BGL 3 2018-08-28T11:44:55+05:30 Microsoft® Word 2010 2018-08-28T11:44:55+05:30 Microsoft® Word 2010 tetml={filename={D:\Drim\repository\projects\drim_64_0\metadata\6\1\61c765de48675b1c74dac10bf327fdd9\61c765de48675b1c74dac10bf327fdd9.tet.xml} elements={annotations=false bookmarks=false destinations=false fields=false javascripts = false} } granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED (A JOINT VENTURE OF HPCL & GAIL) BID DOCUMENT FOR Tender for Operation and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. UNDER OPEN DOMESTIC COMPETITIVE BIDDING IN TWO BID SYSTEM Bid Document No.: BGL/423/2018-19 VOLUME-I of II granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 REQUEST FOR QUOTATION (RFQ) VOLUME I OF II BID DOCUMENT NO.: BGL/423/2018-19 Date: 28.08.2018 To, CLIENT : Bhagyanagar Gas Limited Item : Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Tender Fee : Rs. 3,540/-( Incl. of GST @18%) (Bidders desirous of submitting their bids on downloaded document have to pay requisite bid document fee through DD as specified in tender document and same as to enclose with Bid Document) Pre –bid meeting date : 06.09.2018 at 1100 Hrs @ BGL-HO, Basheerbagh Due Date & Time : 17.09.2018 at 1500 hrs. (IST) of submission of bid Date & Time of Un price Bid opening : 17.09.2018 at 1600 hrs. (IST) Address : Bhagyanagar Gas Limited 2 nd Floor, APIDC Building Parishram Bhavan, Basheer Bagh, Hyderabad-500 004 Ph No.: 040-23236983 Fax No.: 040-23245081 E-mail: bonnyk.joseph@bglgas.com Contact Person : Bonny K Joseph, Manager (C&P) Validity of Offer : Minimum 3 months from the due date of submission of offer. BID SECURITY DETAILS : a) Bid Security Amount : For Part A: Hyderabad: Rs.7, 84,000 /- (Rupees Seven Lakhs Eighty Four thousand only) For Part B: Vijayawada: Rs.6, 85,000 /- (Rupees Six Lakhs Eighty Five thousand only) b) Validity : Minimum 5 months for Bank Guarantee or 3 Months For DD from the due date of submission of offer. c) Mode : Either in form of Account payee Demand Draft in favour of „Bhagyanagar Gas Limited, payable at Hyderabad, Telangana state of India. OR In form of Bank Guarantee as detailed in tender document. Note: Corrigenda, Addenda, Clarifications etc. if any to the above will be hosted only in BGL website. Bidders should regularly visit the website to keep themselves updated. (Sign & Seal of Bidder) Page 2 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II Gentlemen, 1.0 Bhagyanagar Gas Limited (BGL) is a joint venture of M/s Hindustan Petroleum Corporation Limited (HPCL) and GAIL (India) Limited operating CNG & City Gas Distribution in the states of Telangana and Andhra Pradesh. 2.0 Sealed tenders under Two-bid system are invited for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Sealed tender along with Bid Security should reach Bhagyanagar Gas Limited, Hyderabad on or before the due date and time at the address given above. The bidder should type the Bid format (enclosed) in their own letter without altering/changing the content. 3.0 EVALUATION BASIS Bidder shall quote the rates as per „Schedule of Rates‟ of this tender. Please note that Owner intents to evaluate on estimated quantity basis and finalize the tender on the basis of overall minimum cost to BGL for each part. 4.0 SEALING & MARKING OF BIDS Bids are invited for the item(s) in complete accordance with the Bid Document. Bids should be submitted in sealed envelope super-scribed with the Bid Document Number, due date, item and nature of bid (un-priced, priced). Part – A : i) UNPRICED BID complete with all technical and Commercial details of offer. Each page of offer shall be signed & stamped by bidder. ii) SOR, identical to Part-B of offer with prices blanked out and mentioned as Items Quoted/Not Quoted. iii) Original Copy of tender document along with all Annexure duly signed & stamped on each page as a token of acceptance of all terms & condition. Part - B : ONLY PRICE BID IN DUPLICATE (1 Original +1 Copy), WITH FULL PRICE DETAILS EXACTLY AS PER „SCHEDULE OF RATES‟.NO OTHER DOCUMENT TO BE ENCLOSED as per Cut-Out Slip. Part - C : The original Bid Security of requisite value must be enclosed in another separately sealed envelope duly super-scribed as `Bid Security‟. The three SEALED envelopes, containing Part-A ,Part-B and Part - C of offer respectively, shall be enclosed in a larger envelope duly sealed and pasted with the enclosed CUT-OUT slip at Section 2 of this tender and shall bear the name and address of the bidder. (Sign & Seal of Bidder) Page 3 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 5.0 i) Bid documents are not transferable. Bid received from party other than to whom the tender document was issued, shall be rejected. Bid Document calls for offers on single point “Prime Bidder” responsibility basis. Bidders are therefore advised not to submit offers in “Consortium” or “Joint Bid”. Joint bid referred herein is an offer, which seeks order to be placed on more than one party/co-bidder. ii) Order will be placed on the “Prime Bidder” alone (in whose name the bid document has been issued) who will be responsible for all contractual purposes. The status of all other vendors as may be referred/identified by the Prime Bidder in the offer shall be that of sub-vendor/sub-supplier. The prices once quoted by the bidder shall not be allowed for any subsequent price revision/adjustments at his own. As such, bidders are advised to ensure that their offer is on single bidder responsibility basis is complete as per scope of work/supply as specified in Bid Document. 6.0 Bidder must furnish turnover details for the last three financial years along with their bid. It may please be noted that in case performance is not satisfactory, the offer is liable to be rejected. 7.0 Bidder shall ensure that Bid Security having a validity of 5 months from the bid due date, must accompany the offer. Offer, if not accompanied with Bid Security, shall liable to be rejected. 8.0 Bids complete in all respects should reach on or before the BID DUE DATE AND TIME. Fax/Telex/Telegraphic/ E-Mail bids shall be rejected. 9.0 Bhagyanagar Gas Limited (BGL) reserves the right to reject any or all the bids received, at its discretion without assigning any reason, whatsoever. 10.0 This Request for Quotation (RFQ) is an integral and inseparable part of the enclosed Bid Document 11.0 The bid opening of the un priced part and price part shall be in the presence of representative of bidder who may like to be present in the bid opening and who bring duly authorized letter of authority in the format, enclosed. However date of opening of price part will be intimated to the bidder later on with a notice period of 2 days. 12.0 BIDDER IS ADVISED TO QUOTE STRICTLY AS PER TERMS AND CONDITIONS OF TENDER DOCUMENT AND NOT TO STIPULATE ANY DEVIATION / EXCEPTIONS. BIDDER MAY NOTE THAT TECHNICAL OR COMMERCIAL CLARIFICATIONS NORMALLY WILL NOT BE SOUGHT FOR AFTER THE RECEIPT OF THE BIDS. BIDDERS ARE ADVISED IN THEIR OWN INTEREST TO ADHERE TO ALL THE TECHNICAL AND COMMERCIAL CONDITIONS AS PER BID DOCUMENT. HOWEVER, BGL RESERVES THE RIGHT TO ACCEPT ANY DEVIATION WITH APPROPRIATE COMMERCIAL LOADING IN THE BEST INTEREST OF THE PROJECT. (Sign & Seal of Bidder) Page 4 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 13.0 BGL shall not be responsible for any costs or expenses incurred by Bidder in connection with the preparation or delivery of Bids, including costs and expenses related with visits to the site. 14.0 If the bid due date happens to be a holiday in BGL, the next working day shall be considered for bid due date. 14.0 Offers sent without payment of requisite tender fee will be ignored straightaway. 15.0 Bidders should ensure that bidding document is complete in all respects. In the event that the bidding document or any part thereof is mutilated or missing, the bidder shall notify BGL immediately at the following address: Bhagyanagar Gas Limited, 2nd Floor, Parishram Building APIDC Building Basheerbagh Hyderabad – 500 004 Ph : 040-23236983/ Fax :040-23245081 In the event such written notice is not received at the aforementioned office within Seven (7) days from the date of issue of the bidding document to the bidder, the bidding documents received by the bidder shall be deemed to be complete in all respects. No extension of time shall be granted under any circumstances to any bidder for submission of its bid on the grounds that the bidder did not obtain a complete set of the bidding document. BGL makes no representation or warranty, express or implied, as to the accuracy, correctness and completeness of the information contained in the bidding document. Please specify Bid Document Number in all your correspondence. THIS IS NOT AN ORDER Yours faithfully, FOR AND ON BEHALF OF Bhagyanagar Gas Limited (Bonny K Joseph) Enclosure: Bid Document Manager(C & P). All the supporting documents required as per tender requirement are to be filed properly. No loose papers or attachments are allowed or entertained. (Sign & Seal of Bidder) Page 5 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 CONTENTS VOLUME I OF II SECTION 1 - BIDDERS ELIGIBILITY CRITERIA SECTION 2 - CUT – OUT SLIPS SECTION 3 - INSTRUCTIONS TO BIDDERS SECTION 4 - AGREED TERMS & CONDITIONS SECTION 5 - FORMS & FORMATS VOLUME I OF II i) Bidder‟s General Information ii) Bid Form iii) Bid Security Form iv) Proforma for Contract Performance Security Bank Guarantee v) Contract Form vi) Exception & Deviation vii) Declaration by Bidder viii) Proforma of Letter of Authority for Attending the Bid Opening ix) Proforma of Letter of Authority for attending negotiations and signing agreement. x) Financial Data xi) PF Registration No. Form SECTION 6 - GENERAL CONDITIONS OF CONTRACT (Sign & Seal of Bidder) Page 6 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 SECTION – 1 BIDDERS ELIGIBILITY CRITERIA VOLUME I OF II (Sign & Seal of Bidder) Page 7 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 BEC (BIDDERS‟ ELIGIBILITY CRITERIA) VOLUME I OF II Bidder should furnish documents in support of the following criteria, failing which the offer shall not be considered for bid evaluation: 1.0 BEC-TECHNICAL 1.1 Bidder should have experience of providing CAMC/Operation & Maintenance Services of CNG Compressor packages. 1.2 The Bidder should submit proof of single WO/PO along with Work completion certificate for jobs or works mentioned in Clause no:1.1 of BEC for a minimum value of Rs. 98 Lakhs for PART-A. & Rs.86 Lakhs for PART-B in any of the last Seven (07) years reckoned from bid due date. 1.3 The Bidder shall necessarily have PAN, PF, ESIC and GST registration numbers in its name. Copies should be provided along with the Bid Document. 1.4 Bidder has to submit notarized copies of all the documents pertaining to point No.1.1 &1.2. Note: A. Bidder may quote for one or more Parts depending on qualifying the Bidder‟s eligibility criteria. Bids shall be evaluated on Part wise basis. Bidder quote for both the parts needs to satisfy the criteria / values cumulatively. Bidder quoting for any part must quote for all the items of that Part, otherwise his bid shall be considered as non–responsive and liable to be rejected. B. Bidder must quote of full quantity against each quoted item in the Part mentioned in the Schedule of Rates of tender document; otherwise bidder‟s offer will be liable for rejection. C. It shall be noted that in case bidder fails to submit requisite details/documents, the bid submitted by them is liable to be rejected. D. Bidder not meeting the above technical or financial criteria are advised not to submit the bids. (Sign & Seal of Bidder) Page 8 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 2.0 BEC – FINANCIAL: 2.1 Annual Turnover The minimum annual turnover achieved by the bidder as per their audited financial results in any one of the 3 (three) immediate preceding financial years i.e. FY2014-15, FY 2015-16, FY 2016-17/2017-18 shall be as follows: For SOR – PART-A: Comprehensive Annual Maintenance Contract (AMC) for Delta Compressors in Hyderabad: Rs. 98 Lakhs. For SOR – PART-B: Comprehensive Annual Maintenance Contract (AMC) for Delta Compressors in Vijayawada: Rs. 85.70 Lakhs. 2.2 Net worth Net worth of the bidder should be positive as per the immediate preceding year‟s audited financial results i.e. in FY 2016-17/ FY 2017-18. 2.3 Working Capital The minimum working capital of the bidder as per the immediate preceding year‟s audited financial results i.e. in FY 2016-17/ 17-18 shall be as follows. For SOR – PART-A: Comprehensive Annual Maintenance Contract (AMC) for Delta Compressors in Hyderabad: Rs. 19.60 Lakhs. For SOR – PART-B: Comprehensive Annual Maintenance Contract (AMC) for Delta Compressors in Vijayawada: Rs. 8.57 Lakhs. Note: The above mentioned documents pertaining to BEC- Technical Criteria shall be duly certified/ attested by Notary Public with legible stamp. Documents Required-Financial Criteria 1. Annual Turn-over Bidder(s) shall submit copy of Audited Annual Financial Statement [Balance Sheet and Profit & Loss Account Statement] of any of the three (3) preceding Financial Year(s), as per BEC, along with un-priced bid. 2. Net Worth Bidder(s) shall submit copy of Audited Annual Financial Statement [Balance Sheet and Profit & Loss Account Statement] of last audited Financial Year, as per BEC, along with un-priced bid. 3. Working Capital Bidder(s) shall submit copy of Audited Annual Financial Statement [Balance Sheet and Profit & Loss Account Statement] of last audited Financial Year, as per BEC, along with un-price bid. In case Bidder’s working capital is inadequate, the bidder shall supplement this with a letter (as per Format-10.(B) from the Bidder’s bank having net worth not less than Rs 100Crore, confirming the availability of the line of credit for at least working capital requirement as stated above. (Sign & Seal of Bidder) Page 9 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II Documents to be authenticated/attested/certified Copy of audited annual financial statement (balance sheet and profit & loss account statement) for the corresponding year(s) duly signed and stamped by a chartered accountant and also to be duly certified/ attested by notary public with legible stamp, along with un-price bid. "Details of financial capability of bidder” in prescribed Format-10(A) enclosed duly signed and stamped by a chartered accountant to be submitted) along with un-price bid. 3.0 EVALUATION & AWARDING CRITERIA: The below evaluation will be considered for price evaluation and awarding purpose: 3.1 SOR is divided into two Groups/ Parts: Part-A : Comprehensive AMC (CAMC) of Delta compressors in Hyderabad. Part-B: Comprehensive AMC (CAMC) of Delta compressors in Vijayawada. 3.2 Bidder may quote for any or both group(s) of the Price Schedule. Evaluation and Ordering shall be done group-wise on least cost basis. Bidder quoting for any group shall have to quote for entire quantity (SOR items) of that group otherwise their bid will not be considered. 3.3 Evaluation shall be done separately for SOR- PART-A & SOR-PART- B. (Sign & Seal of Bidder) Page 10 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 SECTION 2 CUT OUT SLIPS VOLUME I OF II (Sign & Seal of Bidder) Page 11 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 (OUTER ENVELOPE) DO NOT OPEN-THIS IS A QUOTATION CLIENT : BHAGYANAGAR GAS LIMITED BID DOCUMENT NO : BGL/423/2018-19 VOLUME I OF II ITEM : Tender for Operations and Comprehensive Annual Maintenance (AMC) of Delta make Compressors of BGL in Hyderabad, & Vijayawada. DUE DATE & TIME : 17.09.2018 at 1500 HRS (IST) NAME: ADDRESS (Sign & Seal of Bidder) Page 12 of 154 TO M/s Bhagyanagar Gas Limited 2 nd Floor, APIDC Building Parishram Bhavan, Basheer Bagh, Hyderabad, Telangana - 500004 Ph No.: +91-040- 23236983 Fax No.: +91-040- 23245081 Kind Attn: Bonny K Joseph Manager (C&P) granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 PART – A (Un Priced Bid) DO NOT OPEN-THIS IS A QUOTATION CLIENT : BHAGYANAGAR GAS LIMITED BID DOCUMENT NO : BGL/423/2018-19 VOLUME I OF II ITEM : Tender for Operations and Comprehensive Annual Maintenance (AMC) of Delta make Compressors of BGL in Hyderabad, & Vijayawada. DUE DATE & TIME : 17.09.2018 at 1500 HRS (IST) NAME: ADDRESS (Sign & Seal of Bidder) Page 13 of 154 TO (To be pasted on the envelope containing “Un Price Bid “) M/s Bhagyanagar Gas Limited 2 nd Floor, APIDC Building Parishram Bhavan, Basheer Bagh, Hyderabad, Telangana - 500004 Ph No.: +91-040- 23236983 Fax No.: +91-040- 23245081 Kind Attn: Bonny K Joseph Manager (C&P) granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 PART – B (Priced Bid) DO NOT OPEN-THIS IS A QUOTATION CLIENT : BHAGYANAGAR GAS LIMITED BID DOCUMENT NO : BGL/423/2018-19 VOLUME I OF II ITEM : Tender for Operations and Comprehensive Annual Maintenance (AMC) of Delta make Compressors of BGL in Hyderabad, & Vijayawada. DUE DATE & TIME : 17.09.2018 at 1500 HRS (IST) NAME: ADDRESS (Sign & Seal of Bidder) Page 14 of 154 TO (To be pasted on the envelope containing “Price Bid”) M/s Bhagyanagar Gas Limited 2 nd Floor, APIDC Building Parishram Bhavan, Basheer Bagh, Hyderabad, Telangana - 500004 Ph No.: +91-040- 23236983 Fax No.: +91-040- 23245081 Kind Attn: Bonny K Joseph Manager (C&P) granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 DO NOT OPEN-THIS IS A QUOTATION CLIENT : BHAGYANAGAR GAS LIMITED BID DOCUMENT NO : BGL/423/2018-19 VOLUME I OF II PART – C (BID SECURITY) ITEM : Tender for Operations and Comprehensive Annual Maintenance (AMC) of Delta make Compressors of BGL in Hyderabad, & Vijayawada. DUE DATE & TIME : 17.09.2018 at 1500 HRS (IST) NAME: ADDRESS (Sign & Seal of Bidder) Page 15 of 154 TO M/s Bhagyanagar Gas Limited 2 nd Floor, APIDC Building Parishram Bhavan, Basheer Bagh, Hyderabad, Telangana - 500004 Ph No.: +91-040- 23236983 Fax No.: +91-040- 23245081 Kind Attn: Bonny K Joseph Manager (C&P) (To be pasted on the envelope containing “Bid Security”) granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 SECTION 3 INSTRUCTIONS TO BIDDERS VOLUME I OF II (Sign & Seal of Bidder) Page 16 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 INSTRUCTION TO BIDDERS INDEX [A] GENERAL: 1. SCOPE OF BID 2. ELIGIBLE BIDDERS 3. BIDS FROM CONSORTIUM / JOINT VENTURE 4. ONE BID PER BIDDER 5. COST OF BIDDING & Tender Fee 6. SITE-VISIT [B] BIDDING DOCUMENTS: 7. CONTENTS OF BIDDING DOCUMENTS 8. CLARIFICATION OF BIDDING DOCUMENTS 9. AMENDMENT OF BIDDING DOCUMENTS [C] PREPARATION OF BIDS: 10. LANGUAGE OF BID 11. DOCUMENTS COMPRISING THE BID 12. SCHEDULE OF RATES / BID PRICES 13 GST (CGST & SGST/ UTGST or IGST ) 14. BID CURRENCIES 15. BID VALIDITY 16. EARNEST MONEY DEPOSIT 17. PRE-BID MEETING 18. FORMAT AND SIGNING OF BID 19. ZERO DEVIATION & REJECTION CRITERIA 20. E-PAYMENT [D] SUBMISSION OF BIDS: 21. SUBMISSION, SEALING AND MARKING OF BIDS 22. DEADLINE FOR SUBMISSION OF BIDS 23. LATE BIDS 24. MODIFICATION AND WITHDRAWAL OF BIDS VOLUME I OF II [E] BID OPENING AND EVALUATION: 25. EMPLOYER'S RIGHT TO ACCEPT ANY BID AND TO REJECT ANY OR ALL BIDS 26. BID OPENING 27. CONFIDENTIALITY 28. CONTACTING THE EMPLOYER 29. EXAMINATION OF BIDS AND DETERMINATION OF RESPONSIVENESS 30. CORRECTION OF ERRORS 31. CONVERSION TO SINGLE CURRENCY FOR COMPARISON OF BIDS 32. EVALUATION AND COMPARISON OF BIDS 33. COMPENSATION FOR EXTENDED STAY 34. PURCHASE PREFERENCE (Sign & Seal of Bidder) Page 17 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II [F] AWARD OF CONTRACT: 35. AWARD 36. NOTIFICATION OF AWARD / FAX OF ACCEPTANCE [FOA] 37. SIGNING OF AGREEMENT 38. CONTRACT PERFORMANCE SECURITY / SECURITY DEPOSIT 39. PROCEDURE FOR ACTION IN CASE CORRUPT/FRAUDULENT/COLLUSIVE/COERCIVE PRACTICES 40. PUBLIC PROCUREMENT POLICY FOR MICRO AND SMALL ENTERPRISE 41. AHR ITEMS 42. VENDOR EVALUATION PROCEDURE 43. INCOME TAX & CORPORATE TAX 44. SETTLEMENT OF DISPUTES BETWEEN GOVERNMENT DEPARTMENT AND ANOTHER AND ONE GOVERNMENT DEPARTMENT AND PUBLIC ENTERPRISE AND ONE PUBLIC ENTERPRISE AND ANOTHER 45. DISPUTE RESOLUTION 46. INAM-PRO (PLATFORM FOR INFRASTRUCTURE AND MATERIALS PROVIDERS) 47. PROMOTION OF PAYMENT THROUGH CARDS AND DIGITAL MEANS 48. CONTRACTOR TO ENGAGE CONTRACT MANPOWER BELONGING TO SCHEDULED CASTES AND WEAKER SECTIONS OF THE SOCIETY 49. QUARTERLY CLOSURE OF THE CONTRACT 50. PROVISION FOR STARTUPS [G] ANNEXURES: 1. ANNEXURE-I: PROCEDURE FOR ACTION IN CASE CORRUPT/FRAUDULENT/COLLUSIVE/COERCIVE PRACTICES 2. ANNEXURE-II: VENDOR PERFORMANCE EVALUATION PROCEDURE 3. ANNEXURE-III : ADDENDUM TO INSTRUCTIONS TO BIDDERS (INSTRUCTION FOR PARTICIPATION IN E-TENDER) (Sign & Seal of Bidder) Page 18 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 INSTRUCTIONS TO BIDDERS [ITB] (TO BE READ IN CONJUNCTION WITH BIDDING DATA SHEET (BDS) 1 SCOPE OF BID [A] – GENERAL VOLUME I OF II 1.1 The Employer as defined in the "General Conditions of Contract [GCC]", wishes to receive Bids as described in the Bidding Document/Tender document issued by Employer. Employer/Owner/BGL occurring herein under shall be considered synonymous. 1.2 SCOPE OF BID: The scope of work/ Services shall be as defined in the Bidding documents. 1.3 The successful bidder will be expected to complete the scope of Bid within the period stated in Special Conditions of Contract. 1.4 Throughout the Bidding Documents, the terms 'Bid', 'Tender'& „Offer‟ and their derivatives [Bidder/Tenderer, Bid/Tender/Offer etc.] are synonymous. Further, 'Day' means 'Calendar Day' and 'Singular' also means 'Plural'. 2 ELIGIBLE BIDDERS 2.1 The Bidder shall not be under a declaration of ineligibility by Employer for Corrupt/ Fraudulent/ Collusive/ Coercive practices, as defined in "Instructions to Bidders [ITB], Clause No. 39” (Action in case Corrupt/ Fraudulent/ Collusive/ Coercive Practices). 2.2 The Bidder is not put on „Holiday‟ by BGL or Public Sector Project Management Consultant (like EIL, Mecon only due to “poor performance” or “corrupt and fraudulent practices”) or banned/blacklisted by Government department/ Public Sector on due date of submission of bid. Further, neither bidder nor their allied agency/(ies) (as defined in the Procedure for Action in case of Corrupt/ Fraudulent/ Collusive/ Coercive Practices) are on banning list of BGL or the Ministry of Petroleum and Natural Gas. If the bidding documents were issued inadvertently/ downloaded from website, offers submitted by such bidders shall not be considered for opening/ evaluation/Award and will be returned immediately to such bidders. In case there is any change in status of the declaration prior to award of contract, the same has to be promptly informed to BGL by the bidder. It shall be the sole responsibility of the bidder to inform BGL in case the bidder is put on „Holiday‟ by BGL or Public Sector Project Management Consultant (like EIL, Mecon. only due to “poor performance” or “corrupt and fraudulent practices”) or banned/blacklisted by Government department/ Public Sector on due date of submission of bid and during the course of finalization of the tender. Concealment of the facts shall tantamount to misrepresentation of facts and shall lead to action against such Bidders as per clause 39 of ITB. 2.3 The Bidder should not be under any liquidation court receivership or similar proceedings on due date of submission of bid. In case there is any change in status of the declaration prior to award of contract, the same has to be promptly informed to BGL by the bidder. (Sign & Seal of Bidder) Page 19 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II It shall be the sole responsibility of the bidder to inform BGL in case the bidder is under any liquidation court receivership or similar proceedings on due date of submission of bid and during the course of finalization of the tender. Concealment of the facts shall tantamount to misrepresentation of facts and shall lead to action against such Bidders as per clause no.39 of ITB. 2.4 Bidder shall not be affiliated with a firm or entity: (i) that has provided consulting services related to the work to the Employer during the preparatory stages of the work or of the project of which the works/services forms a part of or (ii) that has been hired (proposed to be hired) by the Employer as an Engineer/ Consultant for the contract. 2.5 Neither the firm/entity appointed as the Project Management Consultant (PMC) for a contract nor its affiliates/ JV‟S/ Subsidiaries shall be allowed to participate in the tendering process unless it is the sole Licensor/Licensor nominated agent/ vendor. 2.6 Pursuant to qualification criteria set forth in the bidding document, the Bidder shall furnish all necessary supporting documentary evidence to establish Bidder‟s claim of meeting qualification criteria. 2.7 Power of Attorney: In case of a Single Bidder, Power of Attorney issued by the Board of Directors/ CEO /Chairman/ MD / Company Secretary of the Bidder/ all partners in case of Partnership firm/any person authorized in terms of Deed of LLP/Proprietor in favour of the authorised employee(s) of the Bidder, in respect of the particular tender for signing the Bid and all subsequent communications, agreements, documents etc. pertaining to the tender and to act and take any and all decision on behalf of the Bidder, is to be submitted. In case of a Consortium/JV, Power of Attorney issued by Board of Directors/ CEO /Chairman MD / Company Secretary of the Consortium Leader as well as Consortium Member(s) of the Consortium/ partners of JV, in favour of the authorised employee(s) of the Consortium Leader/Lead member of JV, for signing the documents on behalf of the Bidder, in respect of this particular tender, to sign the Bid and all subsequent communications, agreements, documents etc. pertaining to the tender and act and take any and all decision on behalf of the Consortium/JV, are to be submitted. The authorized employee(s) of the Bidder shall be signing the Bid and any consequence resulting due to such signing shall be binding on the Bidder. 3 BIDS FROM "JOINT VENTURE"/"CONSORTIUM" - NOT APPLICABLE. 4 ONE BID PER BIDDER 4.1 A Firm/Bidder shall submit only 'one [01] Bid' in the same Bidding Process. A Bidder who submits or participates in more than 'one [01] Bid' will cause all the proposals in which the Bidder has participated to be disqualified. 4.2 Alternative Bids shall not be considered. (Sign & Seal of Bidder) Page 20 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 5 COST OF BIDDING & TENDER FEE 5.1 COST OF BIDDING VOLUME I OF II The Bidder shall bear all costs associated with the preparation and submission of the Bid including but not limited to Bank charges all courier charges including taxes & duties etc. incurred thereof. Further, BGL will in no case, be responsible or liable for these costs, regardless of the outcome of the bidding process. 5.2 TENDER FEE 5.2.1 Tender Fee, if applicable, will be acceptable in the form of „crossed payee accounts only‟ Bank Drafts/Banker‟s Cheque [in favor of Bhagyanagar Gas Limited payable at Hyderabad]. The Tender Fee is to be submitted as per Clause No. 2.0 (F) & 4.0 of IFB . A Bid without requisite Tender Fee will be ignored straightaway. 5.3 SMEs (Small & Micro Enterprises) are exempted from submission of Tender Fee in accordance with the provisions of Public Procurement Policy for MSE- 2012 and Clause 40 of ITB . The Government Departments/PSUs are also exempted from the payment of tender fee. 5.4 In the event of a particular tender being cancelled, the tender fee (excluding GST thereupon, if any) will be refunded to the concerned bidders without any interest charges. No plea on interest charges in this regard shall be entertained by the Owner. 6.0 SITE VISIT 6.1 The Bidder is advised to visit and examine the site of works and its surroundings and obtain for itself on its own responsibility all information that may be necessary for preparing the Bid and entering into a Contract for the required job. The costs of visiting the site shall be borne by the Bidder. 6.2 The Bidder or any of its personnel or agents shall be granted permission by the Employer to enter upon its premises and land for the purpose of such visits, but only upon the express conditions that the Bidder, its personnel and agents will release and indemnify the Employer and its personnel, agents from and against all liabilities in respect thereof, and will be responsible for death or injury, loss or damage to property, and any other loss, damage, costs, and expenses incurred as a result of inspection. 6.3 The Bidder shall not be entitled to hold any claim against BGL for non-compliance due to lack of any kind of pre-requisite information as it is the sole responsibility of the Bidder to obtain all the necessary information with regard to site, surrounding, working conditions, weather etc. on its own before submission of the bid (Sign & Seal of Bidder) Page 21 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 [B] – BIDDING DOCUMENTS VOLUME I OF II 7 CONTENTS OF BIDDING DOCUMENTS 7.1 The contents of Bidding Documents / Tender Documents are those stated below, and should be read in conjunction with any 'Addendum / Corrigendum' issued in accordance with "ITB: Clause-9": ‣ Section-I : BID EVALUATION CRITERIA [BEC] & Evaluation methodology ‣ Section-II : Cut-out Slips ‣ Section-III : Instructions to Bidders [ITB] Annexure Forms & Format ‣ Section-IV : Agree Terms and Conditions ‣ Section-V : Forms & Format ‣ Section-VI : General Conditions of Contract [GCC] ‣ Section-VII: Service Requisation ‣ Section-VIII: Scope of Work ‣ Section-IX : Special Conditions of Contract [SCC] ‣ Section-X : Schedule of Rates *Request for Quotation‟, wherever applicable, shall also form part of the Bidding Document. 7.2 The Bidder is expected to examine all instructions, forms, terms & conditions in the Bidding Documents. The "Request for Quotation [RFQ] &Invitation for Bid (IFB)" together with all its attachments thereto, shall be considered to be read, understood and accepted by the Bidders. Failure to furnish all information required by the Bidding Documents or submission of a Bid not substantially responsive to the Bidding Documents in every respect will be at Bidder's risk and may result in the rejection of his Bid. 8 CLARIFICATION OF BIDDING DOCUMENTS 8.1 A prospective Bidder requiring any clarification(s) of the Bidding Documents may notify BGL in writing or by fax or email at BGL's mailing address indicated in the BIDS no later than 02 (two) days prior to pre-bid meeting (in cases where pre-bid meeting is scheduled) or 05 (five) days prior to the due date of submission of bid in cases where pre-bid meeting is not held. BGL reserves the right to ignore the bidders request for clarification if received after the aforesaid period. BGL may respond in writing to the request for clarification. BGL's response including an explanation of the query, but without identifying the source of the query will be uploaded on BGL‟s tendering web site [http://www.bglgas.com/ and Government Website] / communicated to prospective bidders by e-mail/ fax. 8.2 Any clarification or information required by the Bidder but same not received by the Employer at clause 8.1 above is liable to be considered as "no clarification / information required". (Sign & Seal of Bidder) Page 22 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 9 AMENDMENT OF BIDDING DOCUMENTS VOLUME I OF II 9.1 At any time prior to the 'Bid Due Date', Owner may, for any reason, whether at its own initiative or in response to a clarification requested by a prospective Bidder, modify the Bidding Documents by addenda/ corrigendum. 9.2 Any addendum/ corrigendum thus issued shall be integral part of the Tender Document and shall be hosted on the websites as provided at clause no. 2.0 (G) of IFB /communicated to prospective bidders by e-mail/ fax. Bidders have to take into account all such addendum/ corrigendum before submitting their Bid. 9.3 The Employer, if consider necessary, may extend the date of submissions of Bid in order to allow the Bidders a reasonable time to furnish their most competitive bid taking into account the amendment issued thereof. 10 LANGUAGE OF BID: [C] – PREPARATION OF BIDS The bid prepared by the Bidder and all correspondence, drawing(s), document(s), certificate(s) etc. relating to the Bid exchanged by Bidder and BGL shall be written in English language only. In case a document, certificate, printed literature etc. furnished by the Bidder in in a language other than English, the same should be accompanied by an English translation duly authenticated by the Chamber of Commerce of Bidders Country, in which case, for the purpose of interpretation of the Bid, the English translation shall govern. 11. DOCUMENTS COMPRISING THE BID 11.1 In case the Bids are invited under the Manual two Bid system. The Bid prepared by the Bidder shall comprise the following components sealed in 2 different envelopes: 11.2. Envelope-I: Superscribing Techno-Commercial Un Price Bid (PART- A) 11.2.1 Part – A: Techno-commercial / Un Priced bid and shall contain the following duly signed on each page. i. Covering letter. ii. Bidder‟s General Details/information iii. Power of Attorney in favour of person (s) signing the bid that such person (s) is/are authorised to sign the bid on behalf of the bidder and any consequence resulting due to such signing shall be binding on the bidder. iv. Bid Form as per F-2 v. Bid security/EMD in accordance with Clause 16 of “ITB” shall be furnished in Original in the form of Banker‟s Cheque /Bank Draft payable to Bhagyanagar Gas Limited at Hyderabad or Bank Guarantee as per FORM F-3. (To be separately kept in envelope-III.) vi. Duly attested documents in accordance with the "BID EVALUATION CRITERIA [BEC]" establishing the qualification. vii. Details of similar work done and Specific experience during past seven years. (Sign & Seal of Bidder) Page 23 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II viii. Annual Turnover details as called for in qualifying requirements as per FORM F- 10(A). ix. Compliance to Bid Requirement/Exception Deviation Statement as per Proposal FORM F-6. x. Details of PF Registration No as per the proposal FORM F-11. xi. Reply to Commercial Questionnaire/Agreed Terms & Conditions Section-4. xii. Letter of authority in original physical form in favour of any one of bidder‟s executive having authority to attend the un-priced & Priced bid opening on specified dates and venue as per FORM F-8,9. xiii. Copies of documents defining constitution or legal status, place of registration and principal place of business of the Company. xiv. Bidder‟s declaration that they are not under any liquidation, court receiver ship or similar proceedings. xv. Technical details/documents as per bidding document. xvi. Any other information/ details required as per requirement of bidding documents. xvii. Copy of Bidding Documents along with addendum/corrigendum no. duly signed and sealed on each page, in token of confirmation that Bid Documents are considered in full while preparing the bid and in case of award, work will be executed in accordance with the provisions detailed in Bidding Documents Note: All the pages of the Bid must be signed by the "Authorized Signatory" of the Bidder. 11.3. Envelope II: Super scribing “Price Bid - Not to open with Techno –Commercial Un Price Bid”-PART- B. The Prices are to be submitted strictly as per the Schedule of Rate of the bidding documents. BGL shall not be responsible for any failure on the part of the bidder to follow the instructions. Bidders are advised NOT to mention Rebate/Discount separately, either in the SOR format or anywhere else in the offer. In case Bidder(s) intend to offer any Rebate/Discount, they should include the same in the item rate(s) itself under the “Schedule of Rates (SOR)” and indicate the discounted unit rate(s) only. i) If any unconditional rebate has been offered in the quoted rate the same shall be considered in arriving at evaluated price. However no cognizance shall be taken for any conditional discount for the purpose of evaluation of the bids. ii) In case, it is observed that any of the bidder(s) has/have offered suo-moto Discount/Rebate after opening of unpriced bid but before opening of price bids such discount /rebate(s) shall not be considered for evaluation. However, in the event of the bidder emerging as the lowest evaluated bidder without considering the discount/rebate(s), then such discount/rebate(s) offered by the bidder shall be considered for Award of Work and the same will be conclusive and binding on the bidder. iii) In the event as a result of techno-commercial discussions or pursuant to seeking clarifications / confirmations from bidders, while evaluating the un- priced part of the bid, any of the bidders submits a sealed envelope stating that (Sign & Seal of Bidder) Page 24 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II it contains revised prices; such bidder(s) will be requested to withdraw the revised prices failing which the bid will not be considered for further evaluation. iv) In case any bidder does not quote for any item(s) of “Schedule of Rates” and the estimated price impact is more than 10% of the quoted price, then the bid will be rejected. If such price impact of unquoted items is 10% or less of his quoted price, then the unquoted item(s) shall be loaded highest of the price quoted by the other bidders . If such bidder happens to be lowest evaluated bidder, price of unquoted items shall be considered as included in the quoted bid price. v) The Prices are to be filled strictly in the Schedule of Rate of the bidding documents and provision mentioned hereinabove. vi) In case of bids invited under single bid system, a single envelope containing all documents specified at Clause 11.1.1 & 11.1.2 of ITB above form the BID. All corresponding conditions specified at Clause 11.1.1 & 11.1.2 of ITB shall become applicable in such a case. 11.5.1 Envelope III - Part- C: Super scribing “Bid Security” - shall contain Bid Security in original of requisite amount as per RFQ.Bidders are required to submit the EMD in original by Due Date and Time of Bid Submission or upload a scanned copy of the same in the Part-I of the Bid. If the Bidder is unable to submit EMD in original by Due Date and Time of Bid Submission, the Bidder is required to upload a scanned copy of the EMD in Part- I of Bid, provided the original EMD, copy of which has been uploaded, is received within 7 days from the Due Date of Bid Opening, failing which the Bid will be rejected irrespective of their status/ranking in tendering process and notwithstanding the fact that a copy of EMD was earlier uploaded by the Bidder. 12 SCHEDULE OF RATES / BID PRICES 12.1 Unless stated otherwise in the Bidding Documents, the Contract shall be for the whole works as described in Bidding Documents, based on the rates and prices submitted by the Bidder and accepted by the Employer. The prices quoted by the Bidders will be inclusive of all taxes except GST (CGST & SGST/UTGST or IGST). 12.2 Prices must be filled in format for "Schedule of Rates [SOR]" enclosed as part of Tender document. If quoted in separate typed sheets and any variation in item description, unit or quantity is noticed; the Bid is liable to be rejected. 12.3 Bidder shall quote for all the items of "SOR" after careful analysis of cost involved for the performance of the completed item considering all parts of the Bidding Document. In case any activity though specifically not covered in description of item under "SOR" but is required to complete the works as per Specifications, Scope of Work / Service, Standards, General Conditions of Contract (“GCC"), Special Conditions of Contract ("SCC") or any other part of Bidding Document, the prices quoted shall deemed to be inclusive of cost incurred for such activity. 12.4 All duties, taxes and other levies [if any] payable by the Contractor under the Contract, or for any other cause except final GST (CGST & SGST/UTGST or IGST) shall be included in the rates / prices and the total bid-price submitted by the (Sign & Seal of Bidder) Page 25 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II Bidder. Applicable rate of GST (CGST & SGST/ UTGST or IGST) on the contract value shall be indicated in Agreed Terms & Conditions (Format-F 4) and SOR. 12.5 Prices quoted by the Bidder, shall remain firm and fixed and valid until completion of the Contract and will not be subject to variation on any account. Any new taxes & Duties, if imposed by the State/ Govt. of India after due date of bid submission but before the Contractual Delivery Date, shall be reimbursed to the contractor on submission of documentary evidence for proof of payment to State/ Govt. Authorities and after ascertaining it‟s applicability with respect to the contract. 12.6 The Bidder shall quote the prices in 'figures' & words. There should not be any discrepancy between the prices indicated in figures and the price indicated in words. In case of any discrepancy, the same shall be dealt as per clause no. 30 of ITB. 12.7 Further, Bidder shall also mention the Service Accounting Codes (SAC) / Harmonized System of Nomenclature (HSN) at the designated place in SOR. 13 GST (CGST & SGST/UTGST or IGST) 13.1 Bidders are required to submit copy of the GST Registration Certificate while submitting the bids wherever GST (CGST & SGST/UTGST or IGST) is applicable. 13.2 Quoted prices should be inclusive of all taxes and duties, except GST (CGST & SGST or IGST or UTGST).Please note that the responsibility of payment of GST (CGST & SGST or IGST or UTGST) lies with the Supplier of Goods / Services only. Supplier of Goods / Services (Service Provider) providing taxable service shall issue an Invoice/ Bill, as the case may be as per rules/ regulation of GST. Further, returns and details required to be filled under GST laws & rules should be timely filed by Supplier of Goods / Services (Service Provider) with requisite details. Payments to Service Provider for claiming GST (CGST & SGST/UTGST or IGST) amount will be made provided the above formalities are fulfilled. Further, BGL may seek copies of challan and certificate from Chartered Accountant for deposit of GST (CGST & SGST/UTGST or IGST) collected from Owner. 13.3 In case CBEC (Central Board of Excise and Customs)/ any equivalent Central Government agency/ State Government agency brings to the notice of BGL that the Supplier of Goods / Services (Service Provider) has not remitted the amount towards GST (CGST & SGST/UTGST or IGST)collected from BGL to the government exchequer, then, that Supplier of Goods / Services (Service Provider) shall be put under Holiday list of BGL for period of six months as mentioned in Procedure for Evaluation of Performance of Vendors/ Suppliers/ Contractors/ Consultants. 13.4 In case of statutory variation in GST (CGST & SGST/UTGST or IGST), other than due to change in turnover, payable on the contract value during contract period, the Supplier of Goods / Services (Service Provider) shall submit a copy of the 'Government Notification' to evidence the rate as applicable on the Bid due date and on the date of revision. Beyond the contract period, in case BGL is not entitled for input tax credit of GST (CGST & SGST/UTGST or IGST), then any increase in the rate of GST (CGST & SGST/UTGST or IGST) beyond the contractual delivery period shall be to Service (Sign & Seal of Bidder) Page 26 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II Provider‟s account whereas any decrease in the rate GST (CGST & SGST/UTGST or IGST) shall be passed on to the Owner. Beyond the contract period, in case BGL is entitled for input tax credit of GST (CGST & SGST/UTGST or IGST), then statutory variation in applicable GST (CGST & SGST/UTGST or IGST) on supply and on incidental services, shall be to BGL‟s account. Claim for payment of GST (CGST & SGST/UTGST or IGST)/ Statutory variation, should be raised within two [02] months from the date of issue of 'Government Notification' for payment of differential (in %) GST (CGST & SGST/UTGST or IGST), otherwise claim in respect of above shall not be entertained for payment of arrears. The base date for the purpose of applying statutory variation shall be the Bid Due Date. 13.5 Where the BGL is entitled to avail the input tax credit of GST (CGST & SGST/UTGST or IGST):- 13.5.1 Owner/BGL will reimburse the GST (CGST & SGST/UTGST or IGST)to the Supplier of Goods / Services(Service Provider) at actuals against submission of Invoices as per format specified in rules/ regulation of GST to enable Owner/BGL to claim input tax credit of GST (CGST & SGST/UTGST or IGST)paid. In case of any variation in the executed quantities, the amount on which the GST (CGST & SGST/UTGST or IGST)is applicable shall be modified in same proportion. Returns and details required to be filled under GST laws & rules should be timely filed by supplier with requisite details. 13.5.2 The input tax credit of GST (CGST & SGST/UTGST or IGST) quoted shall be considered for evaluation of bids, as per evaluation criteria of tender document. 13.6 Where the BGL is not entitled to avail/take the full input tax credit of GST (CGST & SGST/UTGST or IGST):- 13.6.1 Owner/BGL will reimburse GST (CGST & SGST/UTGST or IGST)to the Supplier of Goods / Services (Service Provider) at actuals against submission of Invoices as per format specified in rules/ regulation of GST subject to the ceiling amount of GST (CGST & SGST/UTGST or IGST)as quoted by the bidder, subject to any statutory variations, except variations arising due to change in turnover. In case of any variation in the executed quantities (If directed and/or certified by the Engineer-In- Charge) the ceiling amount on which GST (CGST & SGST/UTGST or IGST)is applicable will be modified on pro-rata basis. 13.6.2 The bids will be evaluated based on total price including applicable GST (CGST & SGST/UTGST or IGST). 13.7 BGL will prefer to deal with registered supplier of goods/ services under GST. Therefore, bidders are requested to get themselves registered under GST, it not registered yet. However, in case any unregistered bidder is submitting their bid, their prices will be loaded with applicable GST (CGST & SGST/UTGST or IGST)while evaluation of bid (if applicable as per Govt. Act/ Law in vogue). Where BGL is entitled for input credit of GST (CGST & SGST/UTGST or IGST), the same will be considered for evaluation of bid as per evaluation methodology of tender document. (Sign & Seal of Bidder) Page 27 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 13.8 In case BGL is required to pay entire/certain portion of applicable GST (CGST & SGST/UTGST or IGST) and remaining portion, if any, is to be deposited by Bidder directly as per GST (CGST & SGST/UTGST or IGST) laws, entire applicable rate/amount of GST (CGST & SGST/UTGST or IGST)to be indicated by bidder in the SOR. Where BGL has the obligation to discharge GST (CGST & SGST/UTGST or IGST) liability under reverse charge mechanism and BGL has paid or is /liable to pay GST (CGST & SGST/UTGST or IGST) to the Government on which interest or penalties becomes payable as per GST laws for any reason which is not attributable to BGL or ITC with respect to such payments is not available to BGL for any reason which is not attributable to BGL, then BGL shall be entitled to deduct/ setoff / recover such amounts against any amounts paid or payable by BGL to Contractor / Supplier. 13.9 Contractor shall ensure timely submission of invoice(s) as per rules/ regulations of GST with all required supporting document(s) within a period specified in Contracts/ LOA to enable BGL to avail input tax credit. Further, returns and details required to be filled under GST laws & rules should be timely filed by supplier with requisite details. If input tax credit with respect to GST (CGST & SGST/UTGST or IGST)is not available to BGL for any reason which is not attributable to BGL, then BGL shall not be obligated or liable to pay or reimburse GST (CGST & SGST/UTGST or IGST) charged in the invoice(s) and shall be entitled to / deduct/ setoff /recover the such GST (CGST & SGST/UTGST or IGST UTGST) there upon together with all penalties and interest if any, against any amounts paid or payable by BGL to Supplier of Goods / Services. 13.10 Anti-profiteering clause As per Clause 171 of GST Act it is mandatory to pass on the benefit due to reduction in rate of tax or from input tax credit to the consumer by way of commensurate reduction in prices. The Supplier of Goods / Services may note the above and quote their prices accordingly. 13.11 In case the GST rating of vendor on the GST portal / Govt. official website is negative / black listed, then the bids may be rejected by BGL. Further, in case rating of bidder is negative / black listed after award award of work for supply of goods / services, then BGL shall not be obligated or liable to pay or reimburse GST to such vendor and shall also be entitled to deduct / recover such GST along with all penalties / interest, if any, incurred by BGL. 13.12 GST (CGST & SGST/UTGST or IGST) is implemented w.e.f. 01.07.2017 which subsumed various indirect taxes and duties applicable before 01.07.2017. Accordingly, the provisions of General Condition of Contract relating to taxes and duties which are subsumed in GST are modified to aforesaid provisions mentioned in clause no. 12 and 13 of ITB. 14 BID CURRENCIES: Bidders must submit bid in Indian Rupees only. (Sign & Seal of Bidder) Page 28 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED 15 BID VALIDITY Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 15.1 Bids shall be kept valid for period specified in BDS from the final Due date of submission of bid'. A Bid valid for a shorter period may be rejected by BGL as 'non- responsive'. 15.2 In exceptional circumstances, prior to expiry of the original 'Bid Validity Period', the Employer may request the Bidders to extend the 'Period of Bid Validity' for a specified additional period. The request and the responses thereto shall be made in writing or by fax/email. A Bidder may refuse the request without forfeiture of his EMD. A Bidder agreeing to the request will not be required or permitted to modify his Bid, but will be required to extend the validity of its EMD for the period of the extension and in accordance with "ITB: Clause-16" in all respects. 16 EARNEST MONEY DEPOSIT 16.1 Bid must be accompanied with earnest money (i.e Earnest Money Deposit (EMD) also known as Bid Security) in the form of „Demand Draft‟ / „Banker‟s Cheque‟ [in favour of Bhagyanagar Gas Limited (BGL) payable at place mentioned in bid document] or „Bank Guarantee‟ or „Letter of Credit‟ strictly as per the format given in form F-3 (as the case may be) of the Tender Document. Bidder shall ensure that EMD submitted in the form of „Bank Guarantee‟ or „Letter of Credit‟ should have a validity of at least „two [02] months‟ beyond the validity of the Bid. EMD submitted in the form of „Demand Draft‟ or „Banker‟s Cheque‟ should be valid for three months. Bid not accompanied with EMD, or EMD not in requisite format shall be liable for rejection. The EMD shall be submitted in Indian Rupees only. 16.2 The EMD is required to protect BGL against the risk of Bidder‟s conduct, which would warrant the forfeiture of EMD, pursuant to clause-16.7 of ITB. 16.3 BGL shall not be liable to pay any documentation charges, Bank charges, commission, interest etc. on the amount of EMD. In case EMD is in the form of a „Bank Guarantee‟, the same shall be from any Indian scheduled Bank or a branch of an International Bank situated in India and registered with „Reserve Bank of India‟ as Scheduled Foreign Bank. However, in case of „Bank Guarantee‟ from Banks other than the Nationalized Indian Banks, the Bank must be commercial Bank having net worth in excess of Rs. 100 Crores [Rupees One Hundred Crores] and a declaration to this effect should be made by such commercial Bank either in the „Bank Guarantee‟ itself or separately on its letterhead. 16.4 Any Bid not secured in accordance with “ITB: Clause-16.1 & Clause-16.3” may be rejected by BGL as non-responsive. 16.5 Unsuccessful Bidder‟s EMD will be discharged/ returned as promptly as possible, but not later than „thirty [30] days‟ after finalization of tendering process. (Sign & Seal of Bidder) Page 29 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 16.6 The successful Bidder‟s EMD will be discharged upon the Bidder‟s acknowledging the „Award‟ and signing the „Agreement‟ (if applicable) and furnishing the „Contract Performance Security (CPS)/ Security Deposit‟ pursuant to clause no. 38 of ITB. 16.7 Notwithstanding anything contained herein, the EMD may also be forfeited in any of the following cases: (a) If a Bidder withdraws his Bid during the „Period of Bid Validity‟ (b) If a Bidder has indulged in corrupt/fraudulent /collusive/coercive practice (c) If the Bidder modifies Bid during the period of bid validity (after Due Date and Time for Bid Submission). (d) Violates any other condition, mentioned elsewhere in the Tender Document, which may lead to forfeiture of EMD. (e) In the case of a successful Bidder, if the Bidder fails to: (i) to acknowledge receipt of the “Notification of Award” / Fax of Acceptance [FOA]”, (ii) to furnish “Contract Performance Security / Security Deposit”, in accordance with “ITB: Clause-38” (iii) to accept „arithmetical corrections‟ as per provision of the clause 30 of ITB. 16.8 In case EMD is in the form of „Bank Guarantee‟ or „Letter of Credit‟, the same must indicate the Tender Document No. and the name of Tender Document for which the Bidder is quoting. This is essential to have proper correlation at a later date. 16.9 MSEs (Micro & Small Enterprises) are exempted from submission of EMD in accordance with the provisions of PPP-2012 and Clause 40 of ITB. However, Traders/ Dealers/ Distributors/ Stockiest/ Wholesaler are not entitled for exemption of EMD. The Government Departments/PSUs are also exempted from the payment of EMD. Further, Startups are also exempted from the payment of EMD. 17 PRE-BID MEETING 17.1 The Bidder(s) or his designated representative are invited to attend a "Pre-Bid Meeting" which will be held at address specified in IFB. It is expected that a bidder shall not depute more than 02 representatives for the meeting. 17.2 Purpose of the meeting will be to clarify issues and to answer questions on any matter that may be raised at that stage and give hands-on e-tendering. 17.3 Text of the questions raised and the responses given, together with any responses prepared after the meeting, will be uploaded on BGL e-tendering website against the Tender. Any modification of the Contents of Bidding Documents listed in "ITB: Clause-7.1", that may become necessary as a result of the Pre-Bid Meeting shall be made by the Employer exclusively through the issue of an Addendum / Corrigendum pursuant to "ITB: Clause-9", and not through the minutes of the Pre-Bid Meeting. 17.4 Non-attendance of the Pre-Bid Meeting will not be a cause for disqualification of Bidder. (Sign & Seal of Bidder) Page 30 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 18 FORMAT AND SIGNING OF BID VOLUME I OF II 18.1 The original and all copies of the Bid shall be typed or written in indelible ink [in the case of copies, photocopies are also acceptable] and shall be signed by a person or persons duly authorized to sign on behalf of the Bidder (as per POA). The name and position held by each person signing, must be typed or printed below the signature. All pages of the Bid except for unamended printed literature where entry(s) or amendment(s) have been made shall be initialed by the person or persons signing the Bid. 18.2 The Bid shall contain no alterations, omissions, or additions, unless such corrections are initialed by the person or persons signing the Bid. 19 ZERO DEVIATION AND REJECTION CRITERIA 19.1 ZERO DEVIATION: Deviation to terms and conditions of "Bidding Documents" may lead to rejection of bid. BGL will accept bids based on terms & conditions of "Bidding Documents" only. Bidder may note BGL will determine the substantial responsiveness of each bid to the Bidding Documents pursuant to provision contained in clause 29 of ITB. For purpose of this, a substantially responsive bid is one which conforms to all terms and conditions of the Bidding Documents without deviations or reservations. BGL's determination of a bid's responsiveness is based on the content of the bid itself without recourse to extrinsic evidence. BGL reserves the right to raise technical and/or commercial query(s), if required, may be raised on the bidder(s). The response(s) to the same shall be in writing, and no change in the price(s) or substance of the bids shall be sought, offered or permitted. The substance of the bid includes but not limited to prices, completion, scope, technical specifications, etc. Bidders are requested to not to take any deviation/exception to the terms and conditions laid down in this "Tender Documents", and submit all requisite documents as mentioned in this "Tender Documents", failing which their offer will be liable for rejection. If a bidder does not reply to the queries in the permitted time frame then its bid shall be evaluated based on the documents available in the bid. 19.2 REJECTION CRITERIA: Notwithstanding the above, deviation to the following clauses of Tender document shall lead to summarily rejection of Bid: (a) Firm Price (b) Earnest Money Deposit / Bid Security (c) Specifications & Scope of Work (d) Schedule of Rates / Price Schedule / Price Basis (e) Duration / Period of Contract/ Completion schedule (f) Period of Validity of Bid (g) Price Reduction Schedule (h) Contract Performance Security (i) Guarantee / Defect Liability Period (j) Arbitration / Resolution of Dispute/Jurisdiction of Court (k) Force Majeure & Applicable Laws (l) Integrity Pact, if Applicable (Sign & Seal of Bidder) Page 31 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II (m) Any other condition specifically mentioned in the tender document elsewhere that non-compliance of the clause lead to rejection of bid Note: Further, it is once again reminded not to mention any condition in the Bid which is contradictory to the terms and conditions of Tender document. 20 E-PAYMENT : Not Applcable [D] – SUBMISSION OF BIDS 21 SUBMISSION, SEALING AND MARKING OF BIDS 21.1 In case of e-tendering, bids shall be submitted through e-tender mode in the manner specified elsewhere in tender document. No Manual/ Hard Copy (Original) offer shall be acceptable. 21.2 In case of manual tendering bid must be submitted in sealed envelope. If the envelope is not sealed & marked as per Clause No. 11 of ITB, the employer will assume no responsibility for misplacement or pre-mature opening of the bid. 21.3 All the bids shall be addressed to the owner at address specified in IFB. 21.4 Bids submitted under the name of AGENT/ CONSULTANT/ REPRESENTATIVE/ RETAINER/ ASSOCIATE etc. on behalf of a bidder/ affiliate shall not be accepted. 22 DEADLINE FOR SUBMISSION OF BIDS 22.1 In case of e-bidding, the bids must be submitted through e-tender mode not later than the date and time specified in the tender documents. 22.2 In case of manual tendering EMD along with bid must be submitted within the due date & time. 22.3 BGL may, in exceptional circumstances and at its discretion, extend the deadline for submission of Bids (clause 9 of ITB refers). In which case all rights and obligations of BGL and the Bidders, previously subject to the original deadline will thereafter be subject to the deadline as extended. Notice for extension of due date of submission of bid will be uploaded on BGL‟s website/ communicated to the bidders. 23 LATE BIDS 23.1 Any bids received after the notified date and time of closing of tenders will be treated as late bids. 23.2 In case of e-tendering, e-tendering system of BGL shall close immediately after the due date for submission of bid and no bids can be submitted thereafter. In case of manual tendering, bids received by BGL after the due date for submission of bids shall not be considered. Such late bids shall be returned to the bidder within “10 days” in „unopened conditions‟. The EMD of such bidders shall be returned along with the un-opened bid. In case of e-tendering, where the bid bond/physical (Sign & Seal of Bidder) Page 32 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II documents has been received but the bid is not submitted by the bidder in the e- tendering portal, such bid bond/ physical documents shall be returned immediately. 23.3 Unsolicited Bids or Bids received to address other than one specifically stipulated in the tender document will not be considered for evaluation/ opening/ award if not received to the specified destination within stipulated date & time. 24 MODIFICATION AND WITHDRAWAL OF BIDS 24.1 Modification and withdrawal of bids shall be as follows:- 24.1.1 IN CASE OF E- TENDERING : Not Applicable 24.1.2 IN CASE OF MANUAL BIDDING The bidder may withdraw or modify its bid after bid submission but before the due date for submission as per tender document provided that the written notice of the modification/ substitution/ withdrawal in received by BGL prior to the deadline for submission of bid. 24.2 The modification shall also be prepared, sealed, marked and dispatched in accordance with the provisions of the clause 11 & 22 of ITB with relevant „Cut-Out Slip‟ duly pasted and mentioning on top of the envelope as “MODIFICATION”. In case of withdrawal of bid, the Envelope containing withdrawal letter duly superscribing the envelope as “WITHDRAWAL” and “Tender Document number :….”/ communication regarding withdrawal of bid with “Tender Document number :….”/ must reach concerned dealing official of BGL within Due date & Time of submission of Bid. No bid shall be modified/ withdrawn after the Due Date & Time for Bid submission. 24.3 Any withdrawal/ modification/ substitution of Bid in the interval between the Due Date & Time for Bid submission and the expiration of the period of bid validity specified by the Bidder in their Bid shall result in the Bidder‟s forfeiture of EMD pursuant to clause 16 of ITB and rejection of Bid. 24.4 The latest Bid submitted by the Bidder shall be considered for evaluation and all other Bid(s) shall be considered to be unconditionally withdrawn. 24.5 In case after price bid opening the lowest evaluated bidder (L1) is not awarded the job for any mistake committed by him in bidding or withdrawal of bid or modification of bid or varying any term in regard thereof leading to re-tendering, BGL shall forfeit EMD paid by the bidder and such bidders shall be debarred from participation in re- tendering of the same job(s)/item(s). Further, such bidder will be put on holiday for a period of six months after following the due procedure. 25 EMPLOYER'S RIGHT TO ACCEPT ANY BID AND TO REJECT ANY OR ALL BIDS BGL reserves the right to accept or reject any Bid, and to annul the Bidding process and reject all Bids, at any time prior to award of Contract, without thereby incurring any liability to the affected Bidder or Bidders or any obligations to inform the affected Bidder or Bidders of the ground for BGL's action. However, Bidder if so desire may seek the reason (in writing) for rejection of their Bid to which BGL shall respond quickly. (Sign & Seal of Bidder) Page 33 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED 26 BID OPENING Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 [E] – BID OPENING AND EVALUATION VOLUME I OF II 26.1 Unpriced Bid Opening : BGL will open bids, in the presence of bidders‟ designated representatives who choose to attend, at date, time and location stipulated in the bid document. The bidders‟ representatives, who are present shall sign a bid opening register evidencing their attendance. 26.2 Priced Bid Opening: 26.2.1 BGL will open the price bids of those bidders who meet the qualification requirement and whose bids is determined to be technically and commercially responsive. Bidders selected for opening of their price bids shall be informed about the date of price bid opening. Bidders may depute their authorized representative to attend the bid opening. The bidders‟ representatives, who are present shall sign a register evidencing their attendance and may be required to be present on a short notice. 26.2.2 The price bids of those Bidders who were not found to be techno-commercially responsive shall not be opened in both manual tendering and e-tendering. In case of Manual Tender, the envelope containing Price Bid shall be returned unopened after opening of the price bids of techno-commercially responsive Bidders. 26.3 In case of bids invited under the single bid system, bid shall be opened on the specified due date & time. 27 CONFIDENTIALITY Information relating to the examination, clarification, evaluation and comparison of Bids, and recommendations for the award of a Contract, shall not be disclosed to Bidder(s) or any other persons not officially concerned with such process. 28 CONTACTING THE EMPLOYER 28.1 From the time of Bid opening to the time of award of Contract, if any Bidder wishes to contact the Employer on any matter related to the Bid, it should do so in writing. Information relating to the examination, clarification, evaluation & recommendation for award shall not be disclosed. 28.2 Any effort by the Bidder to influence the Employer in the Employer's 'Bid Evaluation', 'Bid Comparison', or 'Contract Award' decisions may result in the rejection of the Bidder's Bid and action shall be initiated as per procedure in this regard. 29 EXAMINATION OF BIDS AND DETERMINATION OF RESPONSIVENESS 29.1 The owner‟s determination of a bid‟s responsiveness is based on the content of the bid only. Prior to the detailed evaluation of Bids, the Employer will determine whether each Bid:- (Sign & Seal of Bidder) Page 34 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II (a) Meets the "Bid Evaluation Criteria" of the Bidding Documents; (b) Has been properly signed; (c) Is accompanied by the required 'Earnest Money / Bid Security'; (d) Is substantially responsive to the requirements of the Bidding Documents; and (e) Provides any clarification and/or substantiation that the Employer may require to determine responsiveness pursuant to "ITB: Clause-29.2" 29.2 A substantially responsive Bid is one which conforms to all the terms, conditions and specifications of the Bidding Documents without material deviations or reservations or omissions for this purpose employer defines the foregoing terms below:- a) “Deviation” is departure from the requirement specified in the tender documents. b) “Reservation” is the setting of limiting conditions or withholding from complete acceptance of the requirement in the tender documents. c) “Omission” is the failure to submit part or all of the information or documentation required in the tender document. 29.3 A material deviation, reservation or omission is one that, a) If accepted would, i) Affect in any substantial way the scope, quality, or performance of the job as specified in tender documents. ii) Limit, in any substantial way, inconsistent with the Tender Document, the Employer‟s rights or the tenderer‟s obligations under the proposed Contract. b) If rectified, would unfairly affect the competitive position of other bidders presenting substantially responsive bids. 29.4 The employer shall examine all aspects of the bid to confirm that all requirements have been met without any material deviation, reservation or omission. 29.5 If a Bid is not substantially responsive, it may be rejected by the Employer and may not subsequently be made responsive by correction or withdrawal of the of material deviation, reservation or omission. 30 CORRECTION OF ERRORS 30.1 Bids determined to be substantially responsive will be checked by the Employer for any arithmetic errors. Errors will be corrected by the Employer as follows: (i) When there is a difference between the rates in figures and words, the rate which corresponds to the amount worked out by the Bidder (by multiplying the quantity and rate) shall be taken as correct. (ii) When the rate quoted by the Bidder in figures and words tallies but the amount is incorrect, the rate quoted by the contractor shall be taken as correct and not the amount and the amount shall be re-calculated/ corrected accordingly. (Sign & Seal of Bidder) Page 35 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II (iii) When it is not possible to ascertain the correct rate, in the manner prescribed above, the rate as quoted in words shall be adopted and the amount worked out, for comparison purposes 30.2 The amount stated in the bid will be adjusted by the Employer in accordance with the above procedure for the correction of errors. If the bidder does not accept the corrected amount of bid, its bid will be rejected, and the bid security shall be forfeited. 31 CONVERSION TO SINGLE CURRENCY FOR COMPARISON OF BIDS Not Applicable. All bids submitted must be in the currency specified at clause 14 of ITB. 32 EVALUATION AND COMPARISON OF BIDS Bid shall be evaluated as per evaluation criteria mentioned in Section-I of bidding documents. 33 COMPENSATION FOR EXTENDED STAY [FOR APPLICABILITY OF THIS CLAUSE REFER bid document]:- Not Applicable 33.1 In the event of the time of completions of work getting delayed beyond the time schedule indicated in the bidding document plus a grace period equivalent to 1/5 th of the time schedule or 2 months whichever is more, due to reasons solely attributable to Employer, the Contractor shall be paid compensation for extended stay (ESC) to maintain necessary organizational set up and construction tools, tackles, equipment etc. at site of work. 33.2 The bidder is required to specify the rate for ESC on per month basis in the “PRICE PART” of his bid, which shall be considered for loading on total quoted price during price bid evaluation. The loading shall be done of a period of 1/5 th of the time schedule or 1 month whichever is less. In case bidder does not indicate the rate for ESC in price part of his bid, it will be presumed that no ESC is required by the bidder and evaluation shall be carried out accordingly. 34 PURCHASE PREFERENCE Purchase preference to Central government public sector Undertaking and Micro and Small Enterprises (MSEs) shall be allowed as per Government instructions in vogue. 35 AWARD [F] – AWARD OF CONTRACT Subject to "ITB: Clause-29", BGL will award the Contract to the successful Bidder whose Bid has been determined to be substantially responsive and has been determined as the lowest provided that bidder, is determined to be qualified to satisfactorily perform the Contract. (Sign & Seal of Bidder) Page 36 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 36 NOTIFICATION OF AWARD / FAX OF ACCEPTANCE VOLUME I OF II 36.1 Prior to the expiry of „Period of Bid Validity‟, Notification of Award for acceptance of the Bid will be intimated to the successful Bidder by BGL either by Fax / E - mail /Letter or like means defined as the “Fax of Acceptance (FOA)”. The Contract shall enter into force on the date of FOA and the same shall be binding on BGL and successful Bidder (i.e. Contractor/Service Provider). The Notification of Award/FOA will constitute the formation of a Contract. The detailed Letter of Acceptance shall be issued thereafter incorporating terms & conditions of Tender Document, Corrigendum, Clarification(s), Bid and agreed variation(s)/acceptable deviation(s), if any. BGL may choose to issue Notification of Award in form of detailed Letter of Acceptance without issuing FOA and in such case the Contract shall enter into force on the date of detailed Letter of Acceptance only. 36.2 Contract period shall commence from the date of "Notification of Award" or as mentioned in the Notification of Award. The "Notification of Award" will constitute the formation of a Contract, until the Contract has been effected pursuant to signing of Contract as per "ITB: Clause-37". Upon the successful Bidder's / Contractor's furnishing of 'Contract Performance Security / Security Deposit', pursuant to "ITB: Clause-38", BGL will promptly discharge his 'Earnest Money / Bid Security', pursuant to "ITB: Clause-16" 37 SIGNING OF AGREEMENT 37.1 BGL will award the Contract to the successful Bidder, who, within 'fifteen [15] days' of receipt of the same, shall sign and return the acknowledged copy to BGL. 37.2 The successful Bidder/Contractor shall be required to execute an 'Agreement' in the proforma given in this Bidding Document on a 'non-judicial stamp paper' of appropriate value [cost of the 'stamp-paper' shall be borne by the successful Bidder/Contractor] and of 'state' specified in bid document only, within 'fifteen [15] days' of receipt of the "Fax of Acceptance [FOA]" of the Tender by the successful Bidder/Contractor failure on the part of the successful Bidder/Contractor to sign the 'Agreement' within the above stipulated period, shall constitute sufficient grounds for forfeiture of EMD/Security Deposit. 38 CONTRACT PERFORMANCE SECURITY / SECURITY DEPOSIT 38.1 Within 30 days of the receipt of the notification of award/ Fax of Acceptance from BGL, the successful bidder shall furnish the Contract Performance Security (CPS) in accordance with of General Conditions of the Contract. The CPS shall be in the form of either Banker‟s Cheque or Demand Draft or Bank Guarantee or Letter of Credit and shall be in the currency of the Contract. (Sign & Seal of Bidder) Page 37 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 38.2 The contract performance security shall be for an amount equal to specified in bid document towards faithful performance of the contractual obligations and performance of equipment. For the purpose of CPS, Contract/order value shall be exclusive of GST (CGST & SGST/UTGST or IGST) to be reimbursed by the Owner. Bank Guarantee towards CPS shall be from any Indian scheduled bank or a branch of an International bank situated in India and registered with Reserve bank of India as scheduled foreign bank in case of Indian bidder as well as foreign bidder. However, in case of bank guarantees from banks other than the Nationalized Indian banks, the bank must be a commercial bank having net worth in excess of Rs 100 crores and a declaration to this effect should be made by such commercial bank either in the Bank Guarantee itself or separately on its letterhead. This bank guarantee shall be valid for a period as three months beyond the DLP specified in bid document. 38.3 Failure of the successful bidder to comply with the requirements of this article shall constitute sufficient grounds for the annulment of the award and forfeiture of the EMD. 38.4 The CPS has to cover the entire contract value including extra works/services also. As long as the CPS submitted at the time of award take cares the extra works/ services executed and total executed value are within the awarded contract price, there is no need for additional CPS. As soon as the total executed value is likely to burst the ceiling of awarded contract price, the contractor should furnish additional CPS. 38.5 Further, the bidder can submit CPBG on line through issuing bank to BGL directly as per Ministry of Finance (MOF) Department of financial service direction vide letter ref number F.No.7/112/2011-BOA dated 17 th July 2012. In such cases confirmation will not be sought from issuing banker by BGL. 39 PROCEDURE FOR ACTION IN CASE CORRUPT/ FRAUDULENT/COLLUSIVE/ COERCIVE PRACTICES 39.1 Procedure for action in case Corrupt/ Fraudulent/Collusive/Coercive Practices is enclosed at Annexure-I. 39.2 NON-APPLICABILITY OF ARBITRATION CLAUSE IN CASE OF BANNING OF VENDORS/ SUPPLIERS / CONTRACTORS/BIDDERS/ CONSULTANTS INDULGED IN FRAUDULENT/ COERCIVE PRACTICES Notwithstanding anything contained contrary in GCC and other "CONTRACT DOCUMENTS", in case it is found that the Vendors/ Suppliers / Contractors/Bidders/ Consultants indulged in fraudulent/ coercive practices at the time of bidding, during execution of the contract etc., and/or on other grounds as mentioned in BGL‟s “Procedure for action in case Corrupt/ Fraudulent/ Collusive/ Coercive Practices” (Annexure-I), the contractor/bidder shall be banned (in terms of (Sign & Seal of Bidder) Page 38 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II aforesaid procedure) from the date of issuance of such order by Bhagyanagar Gas Limited (BGL) to such Vendors/ Suppliers / Contractors/Bidders/ Consultants. The Vendor/ Supplier / Contractor/ Bidder/Consultant understands and agrees that in such cases where Vendor/ Supplier / Contractor/ Bidder/Consultant has been banned (in terms of aforesaid procedure) from the date of issuance of such order by Bhagyanagar Gas Limited (BGL), such decision of Bhagyanagar Gas Limited (BGL) shall be final and binding on such Vendor/ Supplier / Contractor/ Bidder/Consultant and the „Arbitration clause‟ in the GCC and other "CONTRACT DOCUMENTS" shall not be applicable for any consequential issue /dispute arising in the matter. 40 PUBLIC PROCUREMENT POLICY FOR MICRO AND SMALL ENTERPRISES 40.1 Following provision has been incorporated in tender for MSEs, in line with notification of Government of India, vide Gazette of India proclaiming the Public Procurement Policy on procurement of goods, works and services from Micro and Small Enterprises (MSEs) i) Issue of tender document to MSEs free of cost. ii) Exemption to MSEs from payment of EMD/Bid Security. 40.2 In case bidder is a Micro or Small Enterprise under the Micro, Small and Medium Enterprises Development Act, 2006, the bidder shall submit the following : a) Documentary evidence that the bidder is a Micro or Small Enterprises registered with District Industries Centers or Khadi and Village Industries National Small Industries Corporation or Directorate of Handicrafts and Handloom or any other body specified by Ministry of Micro, Small and Medium Enterprises or Udyog Aadhaar Memorandum. b) If the MSE is owned by SC/ST Entrepreneurs, the bidder shall furnish appropriate documentary evidence in this regard. The above documents submitted by the bidder shall be duly certified by the Chartered Accountant (not being an employee or a Director or not having any interest in the bidder‟s company/firm) and notary public with legible stamp. If the bidder does not provide the above confirmation or appropriate document or any evidence, then it will be presumed that they do not qualify for any preference admissible in the Public Procurement Policy (PPP) 2012. 40.3 If against an order placed by BGL, successful bidder(s) (other than Micro/Small Enterprise) is procuring material/services from their sub-vendor who is a Micro or Small Enterprise registered with District Industries Centers or Khadi and Village Industries Commission or Khadi and Village Industries Board or Coir Board or National Small Industries Corporation or Directorate of Handicrafts and Handloom or any other body specified by Ministry of Micro, Small and Medium Enterprises with prior consent in writing of the purchasing authority/Engineer-in-charge, the details (Sign & Seal of Bidder) Page 39 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II like Name, Registration No., Address, Contact No. details of material & value of procurement made, etc. of such Enterprises shall be furnished by the successful bidder at the time of submission of invoice/Bill. 40.4 The benefit of policy are not extended to the traders/ dealers/ Distributors/ Stockiest/ Wholesalers. 41 AHR ITEMS: In item rate contract where the quoted rates for the items exceed 50% of the estimate rates, such items will be considered as Abnormally High Rates (AHR) items and payment of AHR items beyond the SOR stipulated quantities shall be made at the lowest amongst the following rates: I) Rates as per SOR, quoted by the Contractor/Bidder. II) Rate of the item, which shall be derived as follows: a. Based on rates of Machine and labour as available from the contract (which includes contractor‟s supervision, profit, overheads and other expenses). b. In case rates are not available in the contract, rates will be calculated based on prevailing market rates of machine, material and labour plus 15% to cover contractor‟s supervision profit, overhead & other expenses. 42 VENDOR PERFORMANCE EVALUATION Shall be as stipulated Annexure II to ITB herewith. 43 INCOME TAX & CORPORATE TAX 43.1 Income tax deduction shall be made from all payments made to the contractor as per the rules and regulations in force and in accordance with the Income Tax Act prevailing from time to time. 43.2 Corporate Tax liability, if any, shall be to the contractor‟s account. 43.3 TDS, wherever applicable, shall be deducted as per applicable act/law/rule. 43.4 MENTIONING OF PAN NO. IN INVOICE/BILL As per CBDT Notification No. 95/2015 dated 30.12.2015, mentioning of PAN no. is mandatory for procurement of goods / services/works/consultancy services exceeding Rs. 2 Lacs per transaction. Accordingly, supplier/ contractor/ service provider/ consultant should mention their PAN no. in their invoice/ bill for any transaction exceeding Rs. 2 lakhs. As provided (Sign & Seal of Bidder) Page 40 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II in the notification, in case supplier/ contractor/ service provider/ consultant do not have PAN no., they have to submit declaration in Form 60 along with invoice/ bill for each transaction. Payment of supplier/ contractor / service provider/ consultant shall be processed only after fulfilment of above requirement 44. SETTLEMENT OF DISPUTES BETWEEN GOVERNMENT DEPARTMENT AND ANOTHER AND ONE GOVERNMENT DEPARTMENT AND PUBLIC ENTERPRISE AND ONE PUBLIC ENTERPRISE AND ANOTHER In the event of any dispute or difference relating to the interpretation and application of the provisions of the contracts, such dispute or difference shall be referred by either party for Arbitration to the sole Arbitrator in the Department of Public Enterprises to be nominated by the Secretary to the Government of India in-charge of the Department of Public Enterprises. The Arbitration and Conciliation Act, 1996 shall not be applicable to arbitrator under this clause. The award of the Arbitrator shall be binding upon the parties to the dispute, provided, however, any party aggrieved by such award may make a further reference for setting aside or revision of the award to the Law Secretary, Department of Legal Affairs, Ministry of Law & Justice, Government of India. Upon such reference the dispute shall be decided by the Law Secretary or the Special Secretary / Additional Secretary, when so authorized by the Law Secretary, whose decision shall bind the Parties finally and conclusively. The parties to the dispute will share equally the cost of arbitration as intimated by the Arbitrator. 45 DISPUTE RESOLUTION (ADDENDUM TO PROVISION REGARDING APPLICABLE LAWS AND SETTLEMENT OF DISPUTES OF GCC) 45.1 Bhagyanagar Gas Limited (BGL) has framed the Conciliation Rules 2010 in conformity with supplementary to Part – III of the Indian Arbitration and Conciliation Act 1996 for speedier, cost effective and amicable settlement of disputes through conciliation. Unless otherwise specified, the matters where decision of the Engineer- in-Charge is deemed to be final and binding as provided in the Agreement and the issues/disputes which cannot be mutually resolved within a reasonable time, all disputes shall be settled in accordance with the Conciliation Rules 2010. 45.2 Any dispute(s)/difference(s)/issue(s) of any kind whatsoever between/amongst the Parties arising under/out of/in connection with this contract shall be settled in accordance with the aforesaid rules. 45.3 In case of any dispute(s)/difference(s)/issue(s), a Party shall notify the other Party(ies) in writing about such a dispute(s) / difference(s) / issue(s) between / amongst the Parties and that such a Party wishes to refer the dispute(s)/ difference(s)/ issue(s) to Conciliation. Such Invitation for Conciliation shall contain sufficient information as to the dispute(s)/ difference(s)/ issue(s) to enable the other Party(ies) to be fully informed as to the nature of the dispute(s)/ difference(s)/ issue(s), the amount of monetary claim, if any, and apparent cause(s) of action. (Sign & Seal of Bidder) Page 41 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 45.4 Conciliation proceedings commence when the other Party(ies) accept(s) the invitation to conciliate and confirmed in writing. If the other Party (ies) reject(s) the invitation, there will be no conciliation proceedings. 45.5 If the Party initiating conciliation does not receive a reply within thirty days from the date on which he/she sends the invitation, or within such other period of time as specified in the invitation, he/she may elect to treat this as a rejection of the invitation to conciliate. If he/she so elects, he/she shall inform the other Party(ies) accordingly. 45.6 Where Invitation for Conciliation has been furnished, the Parties shall attempt to settle such dispute(s) amicably under Part-III of the Indian Arbitration and Conciliation Act, 1996 and Bhagyanagar Gas Limited (BGL) Conciliation Rules, 2010. It would be only after exhausting the option of Conciliation as an Alternate Dispute Resolution Mechanism that the Parties hereto shall go for Arbitration. For the purpose of this clause, the option of „Conciliation‟ shall be deemed to have been exhausted, even in case of rejection of „Conciliation‟ by any of the Parties. 45.7 The cost of Conciliation proceedings including but not limited to fees for Conciliator(s), Airfare, Local Transport, Accommodation, cost towards conference facility etc. shall be borne by the Parties equally. 45.8 The Parties shall freeze claim(s) of interest, if any, and shall not claim the same during the pendency of Conciliation proceedings. The Settlement Agreement, as and when reached/agreed upon, shall be signed between the Parties and Conciliation proceedings shall stand terminated on the date of the Settlement Agreement. 46.0 INAM-PRO (PLATFORM FOR INFRASTRUCTURE AND MATERIALS PROVIDERS)-Not Applicable INAM-Pro (Platform for infrastructure and materials providers) is a web based platform for infrastructure provides and materials suppliers and was developed by Ministry of Road Transport and Highways (MoRT&H) with a view to reduce project execution delays on account of supply shortages and inspire greater confidence in contractors to procure cement to start with directly from the manufacturers. Presently, numerous cement companies are registered in the portal and offering cement for sale on the portal with a commitment period of 3 years. These companies have bound themselves by ceiling rates for the entire commitment period, wherein they are allowed to reduce or increase their cement rates any number of times within the ceiling rate, but are not permitted to exceed the said ceiling rate. MoRT&H is expanding the reach of this web-portal by increasing both the product width as well as the product depth. They are working on incorporating 60 plus product categories. The product range will span from large machineries like Earth Movers and Concrete Mixers, to even the smallest items like road studs. MoRT&H intend to turn it into a portal which services every infrastructure development related need of a modern contractor. (Sign & Seal of Bidder) Page 42 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II BGL‟s contractors may use this innovative platform, wherever applicable. The usage of web – Portal is a completely voluntary exercise. The platform, however, can serve as a benchmark for comparison of offered prices and products. 47 Not Applicable. 48 CONTRACTOR TO ENGAGE CONTRACT MANPOWER BELONGING TO SCHEDULED CASTES AND WEAKER SECTIONS OF THE SOCIETY While engaging the contractual manpower, Contractors are required to make efforts to provide opportunity of employment to the people belonging to Scheduled Castes and weaker sections of the society also in order to have a fair representation of these sections. 49. QUARTERLY CLOSURE OF THE CONTRACT During execution of contracts/orders, various issues may arise. In order to timely detect and to address the contractual issue (s) during the execution of contracts, GAIL has introduced a mechanism of quarterly closure of the contract, under which all the issues related to the contract execution will be monitored on quarterly basis for resolution. Vendors/Contractors are required to co-operate with EIC for proper implementation of this mechanism for smooth execution of the contract.” 50.0 Not Applicable (Sign & Seal of Bidder) Page 43 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 PROCEDURE FOR ACTION IN CASE CORRUPT/FRAUDULENT/COLLUSIVE/COERCIVE PRACTICES VOLUME I OF II Annexure-I A Definitions: A.1 “Corrupt Practice” means the offering, giving, receiving or soliciting, directly or indirectly, anything of value to improperly influence the actions in selection process or in contract execution. “Corrupt Practice” also includes any omission for misrepresentation that may mislead or attempt to mislead so that financial or other benefit may be obtained or an obligation avoided. A2 “Fraudulent Practice” means and include any act or omission committed by a agency or with his connivance or by his agent by misrepresenting/ submitting false documents and/ or false information or concealment of facts or to deceive in order to influence a selection process or during execution of contract/ order. A3 “Collusive Practice amongst bidders (prior to or after bid submission)” means a scheme or arrangement designed to establish bid prices at artificial non-competitive levels and to deprive the Employer of the benefits of free and open competition. A.4 “Coercive practice” means impairing or harming or threatening to impair or harm directly or indirectly, any agency or its property to influence the improperly actions of an agency, obstruction of any investigation or auditing of a procurement process. A.5 “Vendor/Supplier/Contractor/Consultant/Bidder” is herein after referred as “Agency” A.6 ”Appellate Authority” shall mean Committee of Directors consisting of Director (Finance) and Director (BD) for works centers under Director (Projects). For all other cases committee of Directors shall consist of Director (Finance) & Director (Projects). A.7 “Competent Authority” shall mean the authority, who is competent to take final decision for Suspension of business dealing with an Agency/ (ies) and Banning of business dealings with Agency/ (ies) and shall be the “Director” concerned. A.8 “Allied Agency” shall mean all the concerns within the sphere of effective influence of banned/ suspended agencies. In determining this, the following factors may be taken into consideration: (a) Whether the management is common; (b) Majority interest in the management is held by the partners or directors of banned/ suspended firm. (c ) substantial or majority shares are owned by banned/ suspended agency and by virtue of this it has a controlling voice. (Sign & Seal of Bidder) Page 44 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II A.9 “Investigating Agency” shall mean any department or unit of BGL investigating into the conduct of Agency/ party and shall include the Vigilance Department of the BGL, Central Bureau of Investigation, State Police or any other agency set up by the Central or state government having power to investigate. B Actions against bidder(s) indulging in corrupt /fraudulent/ collusive/ coercive practice B.1 Irregularities noticed during the evaluation of the bids : If it is observed during bidding process/ bids evaluation stage that a bidder has indulged in corrupt/fraudulent /collusive/coercive practice, the bid of such Bidder (s) shall be rejected and its Earnest Money Deposit (EMD) shall be forfeited. Further, such agency shall be banned for future business with BGL for a period specified in para B 2.2 below from the date of issue of banning order. B.2 Irregularities noticed after award of contract (i) During execution of contract: If an agency, is found to have indulged in corrupt/fraudulent/ collusive/coercive practices, during execution of contract, the agency shall be banned for future business with BGL for a period specified in para B 2.2 below from the date of issue of banning order. The concerned order (s)/ contract(s) where corrupt/fraudulent/collusive practices is observed, shall be suspended with immediate effect by Engineer- in-Charge (EIC)/ Employer whereby the supply/ work/ service and payment etc. will be suspended. The action shall be initiated for putting the agency on banning. After conclusion of process, the order (s)/ contract (s) where it is concluded that such irregularities have been committed shall be terminated and Contract cum Performance Bank Guarantee (CPBG)/ Contract Performance Security(CPS) submitted by agency against such order (s)/ contract (s) shall also be forfeited. The amount that may have become due to the contractor on account of work already executed by him shall be payable to the contractor and this amount shall be subject to adjustment against any amounts due from the contractor under the terms of the contract. No risk and cost provision will be enforced in such cases. (ii) After execution of contract and during Defect liability period (DLP)/ Warranty/Guarantee Period: If an agency is found to have indulged in corrupt/fraudulent/ collusive/coercive practices, after execution of contract and during DLP/ Warranty/Guarantee Period, the agency shall be banned for future business with BGL for a period specified in para B 2.2 below from the date of issue of banning order. Further, the Contract cum Performance Bank Guarantee (CPBG)/ Contract Performance Security (CPS) submitted by agency against such order (s)/ contract (s) shall be forfeited. (Sign & Seal of Bidder) Page 45 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II (iii) After expiry of Defect liability period (DLP)/ Warranty/ Guarantee Period If an agency is found to have indulged in corrupt/ fraudulent/ collusive/ coercive practices, after expiry of Defect liability period (DLP)/ Warranty/ Guarantee Period, the agency shall be banned for future business with BGL for a period specified in para B 2.2 below from the date of issue of banning order. B.2.2 Period of Banning The period of banning of agencies indulged in Corrupt/ Fraudulent/ Collusive/ Coercive Practices shall be as under and to be reckoned from the date of banning order: S. No. Description 1 Misrepresentation/ False information other than pertaining to BEC of tender but having impact on the selection process. 2 2.1 For example, if an agency confirms not being in holiday/ banning list of PSUs/ Govt. Dept., liquidation, bankruptcy & etc. and subsequently it is found otherwise, such acts shall be considered in this category. Corrupt/ Fraudulent (pertaining to BEC of tender) / Collusive/ Coercive Practices If an agency again commits Corrupt/ Fraudulent (pertaining to BEC of tender) /Collusive/ Coercive Practices in subsequent cases after their banning, such situation of repeated offense to be dealt with more severity and following shall be the period of banning: (v) Repeated once (vi) Repeated twice or more 3 Indulged in unauthorized disposal of materials provided by BGL 4 If act of vendor/ contractor is a threat to the National Security Period of banning from the date of issuance of Banning order 02 years 03 years 7 years (in addition to the period already served) 15 years (in addition to the period already served) 7 years C Effect of banning on other ongoing contracts/ tenders 15 years (Sign & Seal of Bidder) Page 46 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II C.1 If an agency is put on Banning, such agency should not be considered in ongoing tenders/future tenders. C.2 However, if such an agency is already executing other order (s)/ contract (s) where no corrupt/fraudulent/ collusive/coercive practice is found, the agency should be allowed to continue till its completion without any further increase in scope except those incidental to original scope mentioned in the contract. C.3 If an agency is put on the Banning List during tendering and no irregularity is found in the case under process: C.3.1 after issue of the enquiry /bid/tender but before opening of Technical bid, the bid submitted by the agency shall be ignored. C.3.2 after opening Technical bid but before opening the Price bid, the Price bid of the agency shall not be opened and BG/EMD submitted by the agency shall be returned to the agency. C.3.3 after opening of price, BG/EMD made by the agency shall be returned; the offer of the agency shall be ignored & will not be further evaluated. If the agency is put on banning list for fraud/ mis-appropriation of facts committed in the same tender/other tender where errant agency emerges as the lowest (L1), then such tender shall also be cancelled and re-invited. D. Procedure for Suspension of Bidder D.1 Initiation of Suspension Action for suspension business dealing with any agency/(ies) shall be initiated by Corporate C&P Department when (i) Vigilance Department based on the fact of the case gathered during investigation by them recommend for specific immediate action against the agency. (ii) Vigilance Department based on the input from Investigating agency, forward for specific immediate action against the agency. (iii) Non performance of Vendor/Supplier/Contractor/Consultant leading to termination of Contract/ Order. D.2 Suspension Procedure: D.2.1 The order of suspension would operate initially for a period not more than six months and is to be communicated to the agency and also to Vigilance Department. Period of suspension can be extended with the approval of the Competent Authority by one month at a time with a ceiling of six months pending a conclusive decision to put the agency on banning list. (Sign & Seal of Bidder) Page 47 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II D.2.2 During the period of suspension, no new business dealing may be held with the agency. D.2.3 Period of suspension shall be accounted for in the final order passed for banning of business with the agency. D.2.4 The decision regarding suspension of business dealings should also be communicated to the agency. D.2.5 If a prima-facie, case is made out that the agency is guilty on the grounds which can result in banning of business dealings, proposal for issuance of suspension order and show cause notice shall be put up to the Competent Authority. The suspension order and show cause notice must include that (i) the agency is put on suspension list and (ii) why action should not be taken for banning the agency for future business from BGL. The competent authority to approve the suspension will be same as that for according approval for banning. D 3 Effect of Suspension of business: Effect of suspension on other on-going/future tenders will be as under: D.3.1 No enquiry/bid/tender shall be entertained from an agency as long as the name of agency appears in the Suspension List. D.3.2 If an agency is put on the Suspension List during tendering: D.3.2.1 after issue of the enquiry /bid/tender but before opening of Technical bid, the bid submitted by the agency shall be ignored. D.3.2.2 after opening Technical bid but before opening the Price bid, the Price bid of the agency shall not be opened and BG/EMD submitted by the agency shall be returned to the agency. D.3.2.3 after opening of price, BG/EMD made by the agency shall be returned; the offer of the agency shall be ignored & will not be further evaluated. If the agency is put on Suspension list for fraud/ mis-appropriation of facts conducted in the same tender/other tender where errant agency emerges as the lowest (L1), then such tender shall also be cancelled and re-invited. D.3.3 The existing contract (s)/ order (s) under execution shall continue. D.3.4 Tenders invited for procurement of goods, works and services shall have provision that the bidder shall submit a undertaking to the effect that (i) neither the bidder themselves nor their allied agency/(ies) are on banning list of BGL or the Ministry of Petroleum and Natural Gas and (ii) bidder is not banned by any Government department/ Public Sector. (Sign & Seal of Bidder) Page 48 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 F. Appeal against the Decision of the Competent Authority: VOLUME I OF II F.1 The agency may file an appeal against the order of the Competent Authority for putting the agency on banning list. The appeal shall be filed to Appellate Authority. Such an appeal shall be preferred within one month from the of receipt of banning order. F.2 Appellate Authority would consider the appeal and pass appropriate order which shall be communicated to the party as well as the Competent Authority. F.3 Appeal process may be completed within 45 days of filing of appeal with the Appellate Authority. G. Wherever there is contradiction with respect to terms of „Integrity pact‟ , GCC and „Procedure for action in case of Corrupt/Fraudulent/ Collusive/Coercive Practice‟, the provisions of „Procedure for action in case of Corrupt/Fraudulent/ Collusive/Coercive Practice‟ shall prevail. (Sign & Seal of Bidder) Page 49 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II Annexure-II PROCEDURE FOR EVALUATION OF PERFORMANCE OF VENDORS/ SUPPLIERS/ CONTRACTORS/ CONSULTANTS 1.0 OBJECTIVE The objective of Evaluation of Performance aims to recognize, and develop reliable Vendors/ Suppliers/ Contractors/ Consultants so that they consistently meet or exceed expectations and requirements. The purpose of this procedure is to put in place a system to monitor performance of Vendors/ Suppliers/ Contractors/ Consultants associated with BGL in Projects and in O&M so as to ensure timely completion of various projects, timely receipt of supplies including completion of works & services for operation and maintenance of operating plants and quality standards in all respects. 2.0 METHODOLOGY i) Preparation of Performance Rating Data Sheet Performance rating data Sheet for each and every Vendor/ Supplier/Contractor/ Consultant for all orders/Contracts with a value of Rs. 7 Lakhs and above is recommended to be drawn up. These data sheets are to be separately prepared for orders/ contracts related to Projects and O&M. Format, Parameters, Process, responsibility for preparation of Performance Rating Data Sheet are separately mentioned. ii) Measurement of Performance Based on the parameters defined in Data Sheet, Performance of concerned Vendor/ Supplier/ Contractor/ Consultant would be computed and graded accordingly. The measurement of the performance of the Party would be its ability to achieve the minimum scoring of 60% points in the given parameters. iii) Initiation of Measures: Depending upon the Grading of Performance, corrective measures would be initiated by taking up the matter with concerned Vendor/ Supplier/ Contractor/ Consultant. Response of Vendor/ Supplier/ Contractor/ Consultant would be considered before deciding further course of action. iv) Implementation of Corrective Measures: Based on the response of Vendor/ Supplier/Contractor/ Consultant, concerned Engineer-in-Charge for the Projects and/or OIC in case of O&M would recommend for continuation or discontinuation of such party from the business of BGL. (Sign & Seal of Bidder) Page 50 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II v) Orders/contracts placed on Proprietary/OEM basis for O&M will be evaluated and, if required, corrective action will be taken for improvement in future. 3.0 PROCESS OF EVALUATION OF PERFORMANCE OF VENDORS/ SUPPLIERS/ CONTRACTORS/ CONSULTANTS 3.1 FOR PROJECTS i) Evaluation of performance of Vendors/ Suppliers/Contractors/ Consultants in case of PROJECTS shall be done immediately with commissioning of any Project. ii) On commissioning of any Project, EIC (Engineer-in-charge)/ Project-in- charge shall prepare a Performance Rating Data Sheet (Format at Annexure-1) for all Orders and Contracts. iii) Depending upon the Performance Rating, following action need to be initiated by Engineer-in-charge/Project-in-charge: Sl.No. Performance Action Rating 1 POOR Seek explanation for Poor performance 2 FAIR Seek explanation for Fair performance 3 GOOD Letter to the concerned for improving performance in future 4 VERY GOOD No further action iv) Reply from concerned Vendor/ Supplier/Contractor/ Consultant shall be examined. In case of satisfactory reply, Performance Rating data Sheet to be closed with a letter to the concerned for improving performance in future. v) When no reply is received or reasons indicated are unsatisfactory, the following actions need to be taken: A) Where Performance rating is “POOR”: Recommend such defaulting Vendor/ Supplier/Contractor/ Consultant for putting on Holiday for a period from one to three years as given below: (i) Poor Performance due to reasons other than Quality : One Year (ii) Poor Performance on account of Quality (if any mark obtained against Quality parameter is less than 30): Two Years (iii) Poor Performance leading to termination of contract or Offloading of contract due to poor performance solely (Sign & Seal of Bidder) Page 51 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II attributable to Vendor/ Supplier/Contractor/ Consultant or Repeated Offence: Three Years Non performance of a Vendor/Supplier/Contractor/Consultant leading to termination of Contract/ Order, such Vendor/ Supplier/ Contractor/Consultant are also to be considered for Suspension. In all such cases, concerned site will put up recommendation for issuance of SCN and putting the party on suspension list as per process defined for suspension in “Procedure for Action in case of Corrupt/ Fraudulent/ Collusive/ Coercive Practices” (B) Where Performance rating is “FAIR”: Recommend for issuance of warning to such defaulting Vendor/ Supplier/Contractor/ Consultant to improve their performance. 3.2 FOR CONSULTANCY JOBS Monitoring and Evaluation of consultancy jobs will be carried out in the same way as described in para 3.1 for Projects. 3.3 FOR OPERATION & MAINTENANCE i) Evaluation of performance of Vendors/ Suppliers/Contractors/ Consultants in case of Operation and Maintenance shall be done immediately after execution of order/ contract. ii) After execution of orders a Performance Rating Data Sheet (Format at Annexure-2) shall be prepared for Orders by Site C&P and for Contracts/Services by respective Engineer-In-Charge. iii) Depending upon Performance Rating, following action need to be initiated by Site C&P: Sl. No. Performance Rating Action 1 POOR Seek explanation for Poor performance 2. FAIR Seek explanation for Fair performance 3 GOOD Letter to the concerned for improving performance in future. 4 VERY GOOD No further action iv) Reply from concerned Vendor/ Supplier/Contractor/ Consultant shall be examined. In case of satisfactory reply, Performance Rating data Sheet to be closed with a letter to the concerned for improving performance in future. v) When no reply is received or reasons indicated are unsatisfactory, the following actions need to be taken: (Sign & Seal of Bidder) Page 52 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 A) Where performance rating is “POOR” VOLUME I OF II Recommend such defaulting Vendor/Supplier/Contractor/ Consultant for putting on Holiday for a period from one to three years as given below: (i) Poor Performance due to reasons other than Quality : One Year (ii) Poor Performance on account of Quality (if any mark obtained against Quality parameter is less than 30): Two Years (iii) Poor Performance leading to termination of contract or Offloading of contract due to poor performance solely attributable to Vendor/Supplier/Contractor/Consultant or Repeated Offence: Three Years Non-performance of a Vendor/Supplier/Contractor/Consultant leading to termination of Contract/ Order such Vendor/ Supplier/ Contractor/Consultant are also to be considered for Suspension. In all such cases, concerned site will put up recommendation for issuance of SCN and putting the party on suspension list as per process defined for suspension in “Procedure for Action in case of Corrupt/ Fraudulent/ Collusive/ Coercive Practices” (B) Where Performance rating is “FAIR” Recommend for issuance of warning to such defaulting Vendors/Contractors/Consultants to improve their performance. 4.0 EXCLUSIONS: The following would be excluded from the scope of evaluation of performance of Vendors/ Suppliers/Contractors/ Consultants: i) Orders/Contracts below the value of Rs. 7 Lakhs. ii) One time Vendor/ Supplier/Contractor/ Consultant. iii) Orders for Misc./Administrative items/ Non stock Non valuated items. However, concerned Engineer-in-Charge /OICs will continue to monitor such cases so as to minimize the impact on Projects/O&M plants due to non performance of Vendors/ Suppliers/Contractors/ Consultants in all such cases. 5.0 REVIEW & RESTORATION OF PARITES PUT ON HOLIDAY 5.1 An order for Holiday passed for a certain specified period shall deemed to have been automatically revoked on the expiry of that specified period and it will not be necessary to issue a specific formal order of revocation. Further, in case Vendor/ Supplier/Contractor/ Consultant is put on holiday due to quality, and new order is placed on bidder after restoration of Vendor/ Supplier/Contractor/ Consultant, such order will be properly monitored during execution stage by the concerned site. (Sign & Seal of Bidder) Page 53 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED 6.0 EFFECT OF HOLIDAY Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 6.1 If a Vendor/ Supplier/Contractor/ Consultant is put on Holiday, such Vendor/ Supplier/Contractor/ Consultant should not be considered in ongoing tenders/future tenders. 6.2 However, if such Vendor/ Supplier/Contractor/ Consultant is already executing any other order/ contract and their performance is satisfactory in terms of the relevant contract, should be allowed to continue till its completion without any further increase in scope except those incidental to original scope mentioned in the contract. In such a case CPBG will not be forfeited and payment will be made as per provisions of concerned contract. However, this would be without prejudice to other terms and conditions of the contract. 6.3. Effect on other ongoing tendering: 6.3.1 after issue of the enquiry /bid/tender but before opening of Technical bid, the bid submitted by the party shall be ignored. 6.3.2 after opening Technical bid but before opening the Price bid, the Price bid of the party shall not be opened and BG/EMD submitted by the party shall be returned to the party. 6.3.3 after opening of price, BG/EMD made by the party shall be returned; the offer of the party shall be ignored & will not be further evaluated. If errant party emerges as the lowest (L1), then such tender shall also be cancelled and re-invited. 7.0 While putting the Vendor/ Supplier/Contractor/ Consultant on holiday as per the procedure, the holding company, subsidiary, joint venture, sister concerns, group division of the errant Vendor/ Supplier/Contractor/ Consultant shall not be considered for putting on holiday list. Any bidder, put on holiday, will not be allowed to bid through consortium route also in new tender during the period of holiday. 8.0 If an unsuccessful bidder makes any vexatious, frivolous or malicious complaint against the tender process with the intention of delaying or defeating any procurement or causing loss to BGL or any other bidder, such bidder will be put on holiday for a period of six months, if such complaint is proved to be vexatious, frivolous or malicious, after following the due procedure. 9. APPEAL AGAINST THE DECISION OF THE COMPETENT AUTHORITY: (a) The party may file an appeal against the order of the Competent Authority for putting the party on Holiday list. The appeal shall be filed to Appellate (Sign & Seal of Bidder) Page 54 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II Authority. Such an appeal shall be preferred within one month from the date of receipt of Holiday order. (b) Appellate Authority would consider the appeal and pass appropriate order which shall be communicated to the party as well as the Competent Authority. (c) Appeal process may be completed within 45 days of filing of appeal with the Appellate Authority. (d) “Appellate Authority” shall mean Committee of Directors consisting of Vice President (Prj. & O&M) and Director Commercial. 10. ERRANT BIDDER In case after price bid opening the lowest evaluated bidder (L1) is not awarded the job for any mistake committed by him in bidding or withdrawal of bid or modification of bid or varying any term in regard thereof leading to re-tendering, BGL shall forfeit EMD paid by the bidder and such bidders shall be debarred from participation in re- tendering of the same job(s)/item(s). Further, such bidder will be put on holiday for a period of six months after following the due procedure. 11. In case CBEC (Central Board of Excise and Customs)/ any equivalent Central Government agency/ State Government agency brings to the notice of BGL that the Supplier of Goods / Services (Service Provider) has not remitted the amount towards GST (CGST & SGST/UTGST or IGST)collected from BGL to the government exchequer, , then party will be put on holiday for a period of six months after following the due procedure. (Sign & Seal of Bidder) Page 55 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 Annexure-2 Bhagyanagar Gas Limited (BGL) PERFORMANCE RATING DATA SHEET (FOR PROJECTS/CONSULTANCY JOBS) i) Location : ii) Order/ Contract No. & date : iii) Brief description of Items : Works/Assignment iv) Order/Contract value (Rs.) : v) Name of Vendor/Supplier/ : Contractor/ Consultant vi) Contracted delivery/ : Completion Schedule vii) Actual delivery/ : Completion date VOLUME I OF II Performance Delivery Quality Reliability Total Parameter Performance Performance Performance# Maximum Marks 40 40 20 100 Marks Allocated (*) Remarks (if any) PERFORMANCE RATING (**) Note : (#) Vendor/Supplier/Contractor/Consultant who seek repeated financial assistance or deviation beyond contract payment term or seeking direct payment to the sub- vendor/sub-contractor due to financial constraints, then „0‟ marks should be allotted against Reliability Performance (*) Allocation of marks should be as per enclosed instructions (**) Performance rating shall be classified as under : Sl. Range (Marks) Rating Signature of No. Authorised Signatory: 1 60 & below POOR 2 61-75 FAIR Name: 3 76-90 GOOD 4 More than 90 VERY Designation: GOOD (Sign & Seal of Bidder) Page 56 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 Instructions for allocation of marks (For O&M) 1. Marks are to be allocated as under : 1.1 DELIVERY/ COMPLETION PERFORMANCE 40 Marks Delivery Period/ Delay in Weeks Marks Completion Schedule a) Upto 3 months Before CDD 40 Delay upto 4 weeks 35 ” 8 weeks 30 ” 10 weeks 25 ” 12 weeks 20 ” 16 weeks 15 More than 16 weeks 0 b) Above 3 months Before CDD 40 Delay upto 4 weeks 35 ” 8 weeks 30 ” 10 weeks 25 ” 16 weeks 20 ” 20 weeks 15 ” 24 weeks 10 More than 24 weeks 0 1.2 QUALITY PERFORMANCE 40 Marks For Normal Cases : No Defects/ No Deviation/ No failure: 40 marks i) Rejection/Defects Marks to be allocated on 10 marks prorata basis for acceptable quantity as compared to total quantity for normal cases ii) When quality Failure of severe nature 0 marks failure endanger - Moderate nature 5 marks system integration - low severe nature 10-25 marks and safety of the system iii) Number of 1. No deviation 5 marks deviations 2. No. of deviations < 2 2 marks 3. No. of deviations > 2 0 marks VOLUME I OF II (Sign & Seal of Bidder) Page 57 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 1.3 RELIABILITY PERFORMANCE 20 Marks A. FOR WORKS/CONTRACTS i) Submission of order acceptance, agreement, PBG, Drawings and other documents within time ii) Mobilization of resources as per Contract and in 4 marks 4 marks time iii) Liquidation of Check-list points 4 marks iv) Compliance to statutory and HS&E requirements or Reliability of Estimates/Design/Drawing etc. in case of Consultancy jobs v) Timely submission of estimates and other documents for Extra, Substituted & AHR items B. FOR SUPPLIES i) Submission of order acceptance, PBG, Drawings and other documents within time ii) Attending complaints and requests for after sales service/ warranty repairs and/ or query/ advice (upto the evaluation period). iii) Response to various correspondence and conformance to standards like ISO iv) Submission of all required documents including Test Certificates at the time of supply 4 marks 4 marks 5 marks 5 marks 5 marks 5 marks VOLUME I OF II (Sign & Seal of Bidder) Page 58 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 SECTION -4 AGREED TERMS AND CONDITIONS VOLUME I OF II (Sign & Seal of Bidder) Page 59 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 Agreed Terms and Conditions VOLUME I OF II Following shall be duly filled in and should be returned by the bidder alongwith each copy of Unpriced part of Bid /Offer. Clauses confirmed hereunder should not be repeated in the Bid. ALL THE COMMERCIAL TERMS & CONDITIONS SHOULD BE INDICATED IN THIS FORMAT ONLY Sl. No. 1 Bidder‟s details: a) Name b) Full address DESCRIPTION BIDDER'S CONFIRMATION (Confirmed/ Not Confirmed) c) Tel No. d) Fax No. e) Email f) Name & designation of the person signing the bid 2 The followings are to be enclosed along with the bid: a) Power of Authority of the person signing the bid b) Letter of Authority of the person attending the bid opening. 3 Bid Security details: a) Name & Address of issuing Bank b) Security No. & Date c) Value (Rs ........................................... ) d) Validity {Valid minimum for Five (5) months from the final date of submission of offer.} e) Details of issuing bank i. Name ii. Full address iii. Tel No. iv. Fax No. v. Email vi. Name & designation of the Contact person. 4 Validity of Bid {Valid minimum for Three (3) months from the final date of submission of offer.} 5 a) Please confirm that the scope of work is complete as per Scope of Work in Bid Document. b) If reply to (a) is 'No', have all 'Exception & Deviation' been furnished in the format attached with bid document. c) Confirm there are no 'Exception & Deviation' other than those indicated as (b) above and if indicated in offer elsewhere the same shall be considered 'NULL & VOID'. 6 Completion period (Sign & Seal of Bidder) Page 60 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} Sl. No. BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II DESCRIPTION BIDDER'S CONFIRMATION (Confirmed/ Not Confirmed) Confirm your acceptance of completion period as per requirement Specified in bid Document. 7 Please confirm that Currency of Offer is Indian Rupees 8 Confirm that all correspondences will be in English language only. 9 Price a) A Copy of Price Format / SOR (without price) but duly filled in with quoted/unquoted word in each cell of format duly signed and stamped to be submitted with un-price part of bid. b) Please confirm that price quoted is as per 'Price Format' given in tender document without any change and submitted with the Price Part of the Bid. c) Confirm quoted prices will remain firm and fixed till complete execution of the order. Fax of Intent (FOI), placed within offer validity, shall be considered as „Notification of Award of Contract‟. d) Confirm that the tender document is carefully studied & understood and quoted price are inclusive of all as per requirements of tender document. e) Rates/ amount must be filled in format for 'Price Schedule/ Schedule of Rates‟ enclosed as part of Bidding Document. If quoted in separate typed sheets and any variation in item description, unit or quantity is noticed, the bid is liable to be rejected. In any case, Bidder shall be presumed to have quoted against the tendered description of work and the same shall be binding on the Bidder. Please confirm. f) Confirm that deviation/ terms & conditions are not mentioned in the price part. In case any terms and condition is mentioned in the price part, the same shall be treated as null and void. 10 Taxes & Duties All taxes, duties, levies, License fee, etc., incurred until completion of the contract period, shall be borne and paid by the bidder. In case of erection/ installation & other site works, all service tax, works contract tax etc (as applicable) shall be considered. The statutory variation in taxes & duties within the contractual period shall be on the owners account. 11 Price Reduction/PENALTY a) Confirm acceptance of Price Reduction/LD/PENALTY as per SCC & GCC of Bid Document. 12 Confirm acceptance of relevant Terms of Payment as specified in the SCC of Bid Document. a) It is noted and confirmed that deviations to 'Terms & Conditions of Payment' shall lead to loading of prices or rejection of offer, as Owner considers fit. (Sign & Seal of Bidder) Page 61 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} Sl. No. BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II DESCRIPTION BIDDER'S CONFIRMATION (Confirmed/ Not Confirmed) b) All the Deviation on 'Payment Terms & Conditions' have been indicated in 'Exception & Deviation' format (including annexure, if any) and have not been repeated in the bid/offer. c) It is confirmed that payment Terms & Conditions indicated elsewhere including any Printed Terms & Conditions, shall not be considered by Owner. 13 GST a) Rate of applicable GST (CGST & SGST/ UTGST or IGST ) b) Whether in the instant tender services/works are covered in reverse charge rule of GST (CGST & SGST/UTGST or IGST) 14 a) Site Work Confirm acceptance of Terms & Conditions for Site work as contained in Scope of Work. b) Confirm acceptance of „Terms & Conditions for Supervision‟ as Contained in Scope of Work in Section 7 of Bid Document. 15 Contract-cum-Performance BG. Confirm that Contract Performance Bank Guarantee for 7.5% of annualized order/contract value (excluding Taxes & Duties) shall be furnished as per provision of bid document, valid till 90 days of expiry of Contract period as per terms of Bid Document. 16 Statutory Clearance Confirm that all Statutory Clearance required are included in his scope of work. 17 Litigation a) Please confirm that your company is not involved in any litigation arbitration during last 5 years. Also confirm that there is no case is filed or pending in any court of law, or tribunal or statutory body. b) If answer to (a) is 'Yes', complete ' details have been separately furnished and enclosed with the offer. 18 Confirm that all document, as per 'Documents comprising the bid / offer by Bidder, have been enclosed. 19 Confirm that owner reserves the right to make any change in the terms & conditions of the Bid Document and to reject any or all bids including those received late or incomplete. CGST: …………… % Plus SGST/UTGST……… % Total: ………………..% Or IGST:…………. % Yes/ No In case of Yes, please specify GST (CGST & SGST/UTGST or IGST) payable by: BGL:………….% Bidder:…………..% (Sign & Seal of Bidder) Page 62 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} Sl. No. BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II DESCRIPTION BIDDER'S CONFIRMATION (Confirmed/ Not Confirmed) 20 Please confirm that all safety rules & regulations as mentioned in bidding document or notified at later date by Employer/Consultant during execution shall be adhered by Contractor within quoted Prices. 21 Please confirm the content / text of SOR is same as per tender document and not modified by the bidder. 22 Confirm that all documents, as per Article - 11 of ITB 'Documents comprising after by Bidder', have been enclosed. 23 Declaration by Bidder a) Confirm acceptance in toto of the Terms & Conditions contained in the bid document. Deviation, if any, has been listed in 'Exception & Deviation' format. b) Confirm that any of the Directors of bidder is not a relative of any Director of Owner or the Bidder is a firm in which any Director of Owner or his relative is a partner or the Bidder is a private company in which any Director of Owner is a member or Director. c) Confirm that you have not been banned or delisted by any Government or Quasi-Government agencies or Public Sector Undertaking. If you have been banned delisted then this fact must be clearly stated. d) Confirm that you are not under liquidation. e) Confirm that you are not in litigation or court receiver ship in any court of laws Bidder confirms that in case of conflicting version of various terms and conditions at different places in his offer, the confirmation furnishes at above shall be dealt as final. Bidder Signature Name Designation (Sign & Seal of Bidder) Page 63 of 154 Seal granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 SECTION -5 PROPOSAL FORMS & FORMATS VOLUME I OF II (Sign & Seal of Bidder) Page 64 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED To Bhagyanagar Gas Limited Parisrama Bhavan APIDC Building, Basheer Bagh Hyderabad – 500 004 Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 BIDDER‟S GENERAL INFORMATION 1-1 Bidder Name :................................................................ 1-2 Number of Years in Operation :................................................................ 1-3 Address of Registered Office :................................................................ City...................................... District........................................ State...................................... PIN/ZIP...................................... 1-4 Operation Address :................................................................ if different from above: ...................................... City...................................... District........................................ State...................................... PIN/ZIP...................................... 1-5 Telephone Number : .................................................................. (Country Code) (Area Code) (Telephone Number) 1-6 E-mail address: :.................................................................. 1-7 Website: :.................................................................. 1-8 Fax Number: :.................................................................. (Country Code) (Area Code) (Telephone Number) 1-9 ISO Certification, if any {If yes, please furnish details} VOLUME I OF II FORM F-1 1-10 Bid Currency :................................................................ ... 1-11 Port of shipment :................................................................... 1-12 Whether Supplier / Manufacturer :................................................................... Dealer/Trader/Contractor 1-13 Type of Material Supplies : :................................................................... 1-14 Banker‟s Name : :................................................................... 1-15 Branch : :................................................................... 1-16 Branch Code : :................................................................... 1-17 Bank account number : :................................................................... (Sign & Seal of Bidder) Page 65 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED ONLY FOR INDIAN BIDDERS Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 1-18 GST No. : :................................................................... 1-19 PAN No. : :................................................................... 1-20 SSI or MSME No : ................................................................... 1-21 Type of Entity : Corporate/ Non-Corporate (As per VOLUME I OF II CGST/SGST/UTGST Act). (In case of Non- Corporate Entity, bidder will submit documentary evidence for same). (Sign & Seal of Bidder) Page 66 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED To Bhagyanagar Gas Limited Parisrama Bhavan APIDC Building, Basheer Bagh Hyderabad – 500 004 Dear Sir, Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 BID FORM VOLUME I OF II FORM F-2 Having examining/reviewing the Bidding Documents for the above Contract, including Conditions of Contract, Specification and Schedule of Rates the receipt of which is hereby duly acknowledged, we, the undersigned, are pleased to bid to execute, complete and maintain the whole of the works as described in, conformity with, the said Bidding Documents, including Addenda Nos............................... We undertake, if our Bid is accepted, to commence the Works within ( ) days, and to complete and deliver the Works in accordance with the Contract within ( ) months calculated from the date of issue of Notification of Award of Works and in accordance with the Time Schedule provided in the bid document. If our bid is accepted, we will provide the performance guarantee equal to 7.5% (Seven Point Five per cent) of the Contract Price, for the due performance of Contract. We agree to abide by this Bid for a period of Three (03) Months from the date fixed for Bid closing / submission and it shall remain binding upon us and may be accepted by any time before the expiration of that period. We have attached the Appendix to the Bid Form duly completed and signed. Until a final contract is prepared and executed, the Bid together with your written acceptance thereof in your notification of award shall constitute a binding Contract between us. We understand that you are not bound to accept the lowest priced or any bid that you may receive. DATE: SEAL AND SIGNATURE Duly authorized to sign bid for and on behalf of..................................................... (SIGNATURE OF WITNESS) WITNESS NAME: ADDRESS: (Sign & Seal of Bidder) Page 67 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II FORM F-3 PROFORMA FOR BANK GUARANTEE FOR EARNEST MONEY DEPOSIT/ BID SECURITY (To be stamped in accordance with the Stamp Act) Ref............... Bank Guarantee No........ Date...................... To Bhagyanagar Gas Limited Parisrama Bhavan APIDC Building, Basheer Bagh Hyderabad – 500 004 Dear Sir(s), In accordance with Invitation for Bid under your reference No...................... M/s........................................................................ having their Registered / Head Office at ................................................. (hereinafter called the Tenderer) wish to participate in the said bidding for ..................................................................................................................... As an irrevocable Bank Guarantee against Earnest Money for the amount of....................... is required to be submitted by the Bidder as a condition precedent for participation in the said bidding which amount is liable to be forfeited on the happening of any contingencies mentioned in the Bidding Document. We, the .....................................................................Bank at............................................. having our Head Office ..................................................................................................... (Local Address) guarantee and undertake to pay immediately on demand without any recourse to the bidder by Bhagyanagar Gas Limited, the amount.................................without any reservation, protest, demur and recourse. Any such demand made by BGL, shall be conclusive and binding on us irrespective of any dispute or difference raised by the Bidder. This guarantee shall be irrevocable and shall remain valid upto ..................... [this date should be 6 months after the date finally set out for closing of bidding]. If any further extension of this guarantee is required, the same shall be extended to such required period on receiving instructions from M/s......................................................................................whose behalf this guarantee is issued. In witness whereof the Bank, through its authorised officer, has set its hand and stamp on this ___________day of ____________20____ at____________. WITNESS: (SIGNATURE) (SIGNATURE) (NAME) (NAME) Designation with Bank Stamp (OFFICIAL ADDRESS) Attorney as per Power of Attorney No................... Date:........................ (Sign & Seal of Bidder) Page 68 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 INSTRUCTIONS FOR FURNISHING BANK GUARANTEE VOLUME I OF II 1. The Bank Guarantee by bidders will be given on non-judicial stamp paper as per stamp duty applicable. The non-judicial stamp paper should be in the name of the issuing bank. In case of foreign bank, the said banks guarantee to be issued by its correspondent bank in India on requisite non-judicial stamp paper. 2. The expiry date as mentioned in bid document should be arrived at by adding 2 months to the date of expiry of the bid validity unless otherwise specified in the Bidding Documents. 3. The bank guarantee by bidders will be given from bank as specified in ITB 4. A letter from the issuing bank of the requisite Bank Guarantee confirming that said bank guarantee /all future communication relating to the Bank Guarantee shall be forwarded to the Employer at its address as mentioned at ITB under intimation to Consultant. 5. Bidders must indicate the full postal address of the bank along with the bank‟s e-mail/ Fax no. from where the earnest money bond has been issued. 6. If a bank guarantee is issued by a commercial bank, then a letter to Employer confirming its net worth is more than Rs. 1,000,000,000/- (Rupees one hundred crore) or equivalent along with a documentary evidence under intimation to Consultant. (Sign & Seal of Bidder) Page 69 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 PROFORMA OF BANK GUARANTEE FOR CONTRACT PERFORMANCE GUARANTEE (ON NON-JUDICIAL PAPER OF APPROPRIATE VALUE) Bhagyanagar Gas Limited Parisrama Bhavan APIDC Building, Basheer Bagh Hyderabad – 500 004 Dear Sirs, VOLUME I OF II FORM F-4 M/s............................................................................................. having registered office at ........................................................................... (hereinafter called the "CONTRACTOR" which expression shall wherever the context so require include its successors and assignees) have been awarded the work of...........................................................................against Work Order ref: ……………of Total Value…………. for Bhagyanagar Gas Limited, Hyderabad. The Contract conditions provide that the CONTRACTOR shall pay a sum of Rs..................... (Rupees ............................................................ only) as Initial/full Contract Performance Guarantee in the form therein mentioned. The form of payment of Contract Performance Guarantee includes guarantee executed by Nationalised Bank, undertaking full responsibility to indemnify Bhagyanagar Gas Limited (hereinafter called "OWNER" which expression shall wherever the context so require, include its successors and assignees) in case of default. The said ............................................................ has approached the BANK (hereinafter called "BANK", which expression shall wherever the context so require include its successors and assignees) and at their request and in consideration of the premises, we, having our office at ............................................................ have agreed to give such guarantee as hereinafter mentioned. 1. We ............................................................ hereby undertake to give the irrevocable and unconditional guarantee with you that if default shall be made by M/s. ............................................................ in performing any of the terms and conditions of the Contract or in payment of any money payable to Bhagyanagar Gas Limited. We shall on first demand without demur, reservation, contest, recourse or protest and/or without reference to the CONTRACTOR pay to OWNER in such manner as OWNER may direct the said amount of Rupees ............................................................ only or such portion thereof not exceeding the said sum as OWNER may from time to time require. 2. OWNER will have the full liberty without reference to us and without affecting this guarantee to postpone for any time or from time to time the exercise of any of the powers and rights conferred on OWNER under the contract with the said CONTRACTOR and to enforce or to forbear from enforcing any powers or rights or by reason of time being given to the said CONTRACTOR and such postponement or forbearance would not have the effect of releasing the BANK from its obligation under this DEBT. (Sign & Seal of Bidder) Page 70 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 3. Your right to recover the said sum of Rs. ............................................................ (Rupees ............................................................ only) from BANK in manner aforesaid will not be affected or suspended by reason of the fact that any dispute or disputes have been raised by the said M/s............................................................ and/or that any dispute or disputes are pending before any officer, tribunal or court and any demand made by OWNER in the BANK shall be conclusive and binding. The BANK shall not be released of its obligations under these presents by any exercise by OWNER of its liberty with reference to matters aforesaid or any of their or by reason or any other acts of omission or commission on the part of OWNER or any other indulgence shown by OWNER or by any other matter or thing whatsoever which under law would, but for this provision, have the effect of releasing the BANK. 4. The guarantee herein contained shall not be determined or affected by the liquidation or winding up, dissolution or change of constitution or insolvency of the CONTRACTOR but shall in all respects and for all purposes be binding and operative until payment of all money due to OWNER in respect of such liabilities is paid. 5. This guarantee shall be irrevocable and shall remain valid upto............................................................ (This date should be 90 (Ninety) days after the expiry of defect liability period) in accordance with the terms of contract which period is deemed to complete on............................................................ The BANK undertakes not to revoke this guarantee during its currency without previous consent of OWNER and further agrees that the Guarantee contained shall continue to be enforceable till the OWNER discharges this guarantee. However, if for any reason, the CONTRACTOR is unable to complete the work within the period stipulated in the contract and in case of extension of the date of completion resulting in extension of defect liability period or the CONTRACTOR fails to perform the work fully, the BANK hereby agrees to further extend this guarantee at the instance of the CONTRACTOR till such time as may be determined by the OWNER. If any further extension of this guarantee is required, the same shall be extended to such required period on receiving instructions from M/s............................................................ on whose behalf this guarantee is issued. 6. The BANK also agrees that OWNER at its option shall be entitled to enforce this guarantee against the surety, as a principal debtor in the first instance without proceeding against CONTRACTOR and not withstanding any security or other guarantee that OWNER may have in relation to the CONTRACTOR's liabilities. 7. The Bank Guarantee's payment of an amount is payable on demand and in any case within 24 hours of the presentation of the letter of invocation of Bank Guarantee. Should the banker fail to release payment on demand, a penal interest of 24% per annum shall become payable immediately and any dispute arising out of or in relation to the said Bank Guarantees shall be subject to the jurisdiction of Hyderabad Courts. (Sign & Seal of Bidder) Page 71 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 8. Therefore, we hereby affirm that we are guarantors and responsible to you on behalf of the Contractor up to a total amount of (amount of guarantees in words and figures) and we undertake to pay you, upon your first written demand declaring the Contractor to be in default under the contract and without caveat or argument, any sum or sums within the limits of (amount of guarantee) as aforesaid, without your needing to prove or show grounds or reasons for your demand or the sum specified therein. This guarantee is valid until the _______day of_______20___. 9. We have power to issue this guarantee in your favour under memorandum and Article of Association and the undersigned has full powers to do so under the Power of Attorney / Resolution of the Board of Directors dated_________ accorded to him by the bank. Place: WITNESS: 1................................................... (Signature) .................................................. (Printed Name) 2.................................................. (Designation) ................................................... (Common Seal) Yours faithfully, (Signature of a person duly authorised to sign on behalf of the Bank) INSTRUCTIONS FOR FURNISHING CONTRACT PERFORMANCE GUARANTEE 1. The Bank Guarantee by successful bidder(s) will be given on non-judicial stamp paper as per stamp duty applicable. The non-judicial stamp paper should be in name of the issuing bank. In case of foreign bank, the said bank guarantee to be issued by its correspondent bank in India on requisite non-judicial stamp paper and place of bid to be considered as Delhi. 2. The bank guarantee by bidders will be given from bank as specified in ITB. 3. A letter from the issuing bank of the requisite Bank Guarantee confirming that said bank guarantee and all future communication relating to the Bank Guarantee shall be forwarded to Employer. 4. If a bank guarantee is issued by a commercial bank, then a letter to Owner confirming its net worth is more than Rs. 1,000,000,000/- (Rupees one hundred Crores). or its equivalent in foreign currency along with a documentary evidence. (Sign & Seal of Bidder) Page 72 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 PROFORMA FOR CONTRACT AGREEMENT VOLUME I OF II FORM F-5 LOA/WO No. BGL / dated ----------- Contract Agreement for the work of ----------------- of BHAGYANAGAR GAS LIMITED. made on ---------- between (Name and Address)------------- , hereinafter called the “CONTRACTOR” (which term shall unless excluded by or repugnant to the subject or context include its successors and permitted assignees) of the one part and BHAGYANAGAR GAS LIMITED hereinafter called the “EMPLOYER” (which term shall, unless excluded by or repugnant to the subject or context include its successors and assignees) of the other part. WHEREAS A. The EMPLOYER being desirous of having provided and executed certain work mentioned, enumerated or referred to in the Tender Documents including Letter Inviting Tender, General Tender Notice, General Conditions of Contract, Special Conditions of Contract, Specifications, Drawings, Plans, Time Schedule of completion of jobs, Schedule of Rates, Agreed Variations, other documents has called for Tender. B. The CONTRACTOR has inspected the SITE and surroundings of WORK specified in the Tender Documents and has satisfied himself by careful examination before submitting his tender as to the nature of the surface, strata, soil, sub-soil and ground, the form and nature of site and local conditions, the quantities, nature and magnitude of the work, the availability of labour and materials necessary for the execution of work, the means of access to SITE, the supply of power and water thereto and the accommodation he may require and has made local and independent enquiries and obtained complete information as to the matters and thing referred to, or implied in the tender documents or having any connection therewith and has considered the nature and extent of all probable and possible situations, delays, hindrances or interferences to or with the execution and completion of the work to be carried out under the CONTRACT, and has examined and considered all other matters, conditions and things and probable and possible contingencies, and generally all matters incidental thereto and ancillary thereof affecting the execution and completion of the WORK and which might have influenced him in making his tender. C. The Tender Documents including the Notice Letter Inviting Tender, General Conditions of Contract, Special Conditions of Contract, Schedule of Rates, General Obligations, SPECIFICATIONS, DRAWINGS, PLANS, Time Schedule for completion of Jobs, Letter of Acceptance of Tender and any statement of agreed variations with its enclosures copies of which are hereto annexed form part of this CONTRACT though separately set out herein and are included in the expression “CONTRACT” wherever herein used. (Sign & Seal of Bidder) Page 73 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED AND WHEREAS Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II The EMPLOYER accepted the Tender of the CONTRACTOR for the provision and the execution of the said WORK at the rates stated in the schedule of quantities of the work and finally approved by EMPLOYER (hereinafter called the "Schedule of Rates") upon the terms and subject to the conditions of CONTRACT. NOW THIS AGREEMENT WITNESSETH AND IT IS HEREBY AGREED AND DECLARED AS FOLLOWS:- 1. In consideration of the payment to be made to the CONTRACTOR for the WORK to be executed by him, the CONTRACTOR hereby covenants with EMPLOYER that the CONTRACTOR shall and will duly provide, execute and complete the said work and shall do and perform all other acts and things in the CONTRACT mentioned or described or which are to be implied there from or may be reasonably necessary for the completion of the said WORK and at the said times and in the manner and subject to the terms and conditions or stipulations mentioned in the contract. 2. In consideration of the due provision execution and completion of the said WORK, EMPLOYER does hereby agree with the CONTRACTOR that the EMPLOYER will pay to the CONTRACTOR the respective amounts for the WORK actually done by him and approved by the EMPLOYER at the Schedule of Rates and such other sum payable to the CONTRACTOR under provision of CONTRACT, such payment to be made at such time in such manner as provided for in the CONTRACT. A N D 3. In consideration of the due provision, execution and completion of the said WORK the CONTRACTOR does hereby agree to pay such sums as may be due to the EMPLOYER for the services rendered by the EMPLOYER to the CONTRACTOR, such as power supply, water supply and others as set for in the said CONTRACT and such other sums as may become payable to the EMPLOYER towards the controlled items of consumable materials or towards loss, damage to the EMPLOYER'S equipment, materials construction plant and machinery, such payments to be made at such time and in such manner as is provided in the CONTRACT. It is specifically and distinctly understood and agreed between the EMPLOYER and the CONTRACTOR that the CONTRACTOR shall have no right, title or interest in the SITE made available by the EMPLOYER for execution of the works or in the building, structures or work executed on the said SITE by the CONTRACTOR or in the goods, articles, materials etc., brought on the said SITE (unless the same specifically belongs to the CONTRACTOR) and the CONTRACTOR shall not have or deemed to have any lien whatsoever charge for unpaid bills will not be entitled to assume or retain possession or control of the SITE or structures and the EMPLOYER shall have an absolute and unfettered right to take full possession of SITE and to remove the CONTRACTOR, their (Sign & Seal of Bidder) Page 74 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II servants, agents and materials belonging to the CONTRACTOR and lying on the SITE. The CONTRACTOR shall be allowed to enter upon the SITE for execution of the WORK only as a licensee simpliciter and shall not have any claim, right, title or interest in the SITE or the structures erected thereon and the EMPLOYER shall be entitled to terminate such license at any time without assigning any reason. The materials including sand, gravel, stone, loose, earth, rock etc., dug up or excavated from the said SITE shall, unless otherwise expressly agreed under this CONTRACT, exclusively belong to the EMPLOYER and the CONTRACTOR shall have no right to claim over the same and such excavation and materials should be disposed off on account of the EMPLOYER according to the instruction in writing issued from time to time by the ENGINEER-IN-CHARGE. In Witness whereof the parties have executed these presents in the day and the year first above written. Signed and Delivered for and on Signed and Delivered for and on behalf of EMPLOYER. on behalf of the CONTRACTORs. BHAGYANAGAR GAS LIMITED (NAME OF THE CONTRACTOR) _______________________________ ____________________________ _______________________________ ____________________________ Date :___________ Date :____________ Place:___________ Place:____________ IN PRESENCE OF TWO WITNESSES 1.___________________________ 1. ______________________ ___________________________ ________________________ ___________________________ ________________________ 2.___________________________ 2. _______________________ ___________________________ ________________________ ___________________________ ________________________ (Sign & Seal of Bidder) Page 75 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED NAME OF WORK : BID DOCUMENT NO. : Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 EXCEPTION AND DEVIATION STATEMENT VOLUME I OF II FORM F-6 Bidder may stipulate exceptions and deviations to Bid Document, if considered unavoidable as per the following format: SL.NO. CLAUSENO. PAGENO.OF TENDER DOCUMENT DEVIATION REASONSFOR DEVIATION Any exceptions/deviations brought out by us elsewhere in our Offer shall not be considered as valid and should be ignored by the Owner / Consultant. NAME OF BIDDER:……………………. SIGNATURE OF BIDDER:……………….… & SEAL Note 1: Bidder is advised not to stipulated deviation to Bid Document until & unless it becomes unavailable. Deviation may lead to rejection of bid and stipulation on „Bid Rejection Criteria‟ given in „Instruction to Bidder‟ of bid document should be read carefully. Note 2: All Techno-Commercial exceptions/deviations taken by Tenderer to the stipulations of the Tender Document shall be brought out here (and not in the other parts of offer Document or price offer). Note 3: Even in case of “No Deviation” this format is to be filled in a „No Deviation‟ & submitted along with the offer (Sign & Seal of Bidder) Page 76 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Bhagyanagar Gas Limited Parisrama Bhavan APIDC Building, Basheer Bagh Hyderabad – 500 004 Dear Sir(s), Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 DECLERATION VOLUME I OF II FORM F-7 1. We confirm and declare that we are not under any liquidation, court receiver ship or similar proceedings. 5. Further we confirm and declare that we have not been put on Holiday by BGL/GAIL/HPCL or not have banned or delisted by any Government or Quasi- Government agencies or Public Sector Undertaking. If you have been banned delisted then this fact must be clearly stated. SIGNATURE OF THE BIDDER:…………………………….. NAME OF THE BIDDER:…………………………….. (Sign & Seal of Bidder) Page 77 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 LETTER OF AUTHORITY VOLUME I OF II FORM F-8 PROFORMA FOR LETTER OF AUTHORITY FOR ATTENDING THEUN-PRICE BIDOPENING AND PRICE BID OPENING No. Date: Bhagyanagar Gas Limited Parisrama Bhavan APIDC Building, Basheer Bagh Hyderabad – 500 004 Dear Sir, We _____________________________________ hereby authorize following representative(s) to attend un-priced bid opening and price bid opening and for any other correspondence and communication against above Bidding Document: Name & Designation _______________________ Signature _________________ Name & Designation _______________________ Signature _________________ We confirm that we shall be bound by all commitments made by aforementioned authorized representatives. Yours faithfully, Signature Name & Designation For and on behalf of Note: This letter of authority should be on the letterhead of the bidder and should be signed by a person competent and having the power of attorney to bind the bidder. Not more than two persons are permitted to attend techno –commercial un-priced and price bid opening. (Sign & Seal of Bidder) Page 78 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 PROFORMA of Letter of Authority for Bid Negotiations and Signing the Agreement No. Date: Bhagyanagar Gas Limited (BGL) Parishram Bhavan, APIDC Building, Basheer Bagh, Hyderabad – 500 004 Attn: Sub: Tender No. Dear Sirs, VOLUME I OF II FORM F-9 We............................................................................................do hereby confirm that (name and address) of Mr. Messers (name and address) is/are authorised to represent us for bid negotiations and to conclude the Agreement on our behalf with you against your above cited tender for………… We confirm that we shall be bound by all and whatsoever our representatives shall commit. Yours faithfully Signature of Mr. Name and Designation Is attested for & on behalf of BIDDER Note: Signature This letter of Authority should be on the letterhead of the Bidders and should be signed by a person competent and having the power of attorney (power of attorney shall be annexed) to bind the bidder. (Sign & Seal of Bidder) Page 79 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 FINANCIAL SITUATION VOLUME I OF II FORM F-10(A) FORMAT FOR CHARTERED ACCOUNTANT CERTIFICATE FOR FINANCIAL CAPABILITY OF THE BIDDER We have verified the Annual Accounts and other relevant records of M/s……….. ……………………………………. (Name of the bidder) and certify the following:- A. ANNUAL TURNOVER OF LAST 3 YEARS Year Amount (Currency) Year 1: 2016-17/2017-18 Year 2: 2015-16 Year 3: 2014-15 B. FINANCIAL DATA FOR LAST AUDITED FINANCIAL YEAR Description Year : .2016-17/2017-18 Amount (Currency) 1. Current Assets 2. Current Liability 3. Working Capital (Current Assets-Current Liability) 4. Net worth (Paid up share capital and Free Reserves & Surplus) Name of Audit Firm/: [Signature of Authorized Signatory] Chartered Accountant Name: Date: Designation: Seal: Membership No.: (Sign & Seal of Bidder) Page 80 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II FORMAT-10(B) FORMAT FOR CERTIFICATION FROM BANK IF THE BIDDER‟S WORKING CAPITAL IS INADEQUATE (To be provided on Bank‟s letter head) Date: Bidder‟s Name: _________________________ Tender No.: ___________________________ To M/s Bhagyanagar Gas Ltd 2 nd Floor,APIDC Building, Parisrama Bhavan, Basheer bagh, Hyderabad – 500004 Dear Sir, Certified that M/s _____________________________ (Name of the bidder with detailed address) is an existing customer of our Bank whose SB/Current Account No. ___________________________. It is confirmed that against Tender No. ............................................... dated ______2018 for “__________________” (job description as per tender document), M/s _____________________ (Name of the Bank with address) confirms availability of line of credit to M/s ________________ (Name of the Bidder) for at least an amount of Rs./ USD ____________ (i.e minimum working capital requirement as per BEC, Vol I. of II) It is also confirmed that the net worth of the Bank is more than INR 1(one) Billion [Rs.100Crores]. Yours Truly, For ___________ (Authorized Signatory) Name of the Signatory: Designation: Registration No. Stamp of Bank Signature of Bidder Name of Bidder: Designation: Seal: (Sign & Seal of Bidder) Page 81 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Bhagyanagar Gas Limited Parisrama Bhavan APIDC Building, Basheer Bagh Hyderabad – 500 004 Dear Sir(s), Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 DETAILS OF P.F. REGISTRATION VOLUME I OF II FORM F-11 We confirm that the following PF account is under operation and shall be used for all PF related activities for the labour engaged by us for the work (awarded to us). PF REGISTRATION NO. : DISTRICT & STATE: SIGNATURE OF THE BIDDER:…………………………….. NAME OF THE BIDDER:…………………………….. (Sign & Seal of Bidder) Page 82 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 SECTION-6 VOLUME I OF II GENERAL CONDITIONS OF CONTRACT (GCC) (Sign & Seal of Bidder) Page 83 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED SECTION-I (DEFINITIONS) 1.0 Definition of Terms Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 GENERAL CONDITIONS OF CONTRACT SECTION-II (GENERAL INFORMATIONS) 2.0 General Information 2.1 (a) Location of Site (b) Access by Road 2.2 Scope of Work 2.3 Water Supply 2.4 Power Supply 2.5 Land for Contractor's field office, Go down and Workshop 2.6 Land for Residential Accommodation SECTION-III (GENERAL INSTRUCTIONS TO TENDERERS) 3.0 Submission of Tender 4.0 Documents 4.1 General 4.2 All pages to be initialed 4.3 Rates to be in figures and words 4.4 Corrections and Erasures 4.5 Signature of Tenderer 4.6 Witness 4.7 Details of Experience 4.8 Liability of Government of India 5.0 Transfer of Tender Documents 6.0 Earnest Money 7.0 Validity 8.0 Addenda/Corrigenda 9.0 Right of Employer to Accept or Reject Tender 10.0 Time Schedule 11.0 Tenderer's Responsibility 12.0 Retired Government or Company Officers 13.0 Signing of the Contract 14.0 Field Management & Controlling/Coordinating Authority 15.0 Note to Schedule of Rates 16.0 void 16.1 Policy for Tenders under consideration 16.2 Zero Deviation 17.0 Award of Contract 18.0 Clarification of Tender Document 19.0 Local Conditions 20.0 Abnormal Rates VOLUME I OF II (Sign & Seal of Bidder) Page 84 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 SECTION-IV (GENERAL OBLIGATIONS) VOLUME I OF II 21.1 Priority of Contract Documents 21.2 Headings & Marginal Notes 21.3 Singular and Plural 21.4 Interpretation 22.0 Special Conditions of Contract 23.0 Contractor to obtain his own information 24.0 Contract Performance Security 25.0 Time of Performance 25.1 Time for Mobilization 25.2 Time Schedule of Construction 26.0 Force Majeure 26.1 Conditions for Force Majeure 26.2 Outbreak of War 27.0 Price Reduction Schedule 27.3 Bonus for Early Completion 28.0 Rights of Employer to forfeit Contract Performance Security 29.0 Failure by the Contractor to comply with the provisions of the contract 30.0 Contractor remains liable to pay compensation if action not taken under Clause 29.0 31.0 Changes in Constitution 32.0 –A Termination of Contract for Death 32.0 -B Termination of Contract for Liquidation, Bankruptcy etc. 32.0 -C Termination of Contract for Non-Performance and subsequently putting theContractor on Holiday 33.0 Members of the Employer not individually liable 34.0 Employer not bound by personal representations 35.0 Contractor's office at site 36.0 Contractor's subordinate staff and their conduct 37.0 Sub letting of Works i) Sub contracts for Temporary works etc. ii) List of sub-contractors to be supplied iii) Contractor's liability not limited by Sub-Contractors iv) Employer may terminate sub contracts v) No remedy for action taken under this clause 38.0 Power of Entry 39.0 Contractor's responsibility with Mechanical, Electrical, Intercommunication System, Air Conditioning Contractors and other agencies 40.0 Other Agencies at site 41.0 Notices 41.1 To the Contractor 41.2 To the Employer 42.0 Rights of various Interests 43.0 Patents and Royalties 44.0 Liens 45.0 Delays by Employer or his authorized agents 46.0 Payments if Contract is terminated 47.0 No waiver of Rights (Sign & Seal of Bidder) Page 85 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 48.0 Certificate not to affect Right of Employer and Liability of Contractor 49.0 Languages & Measures 50.0 Transfer of Title 51.0 Release of Information 52.0 Brand Names 53.0 Completion of Contract 54.0 Spares SECTION-V (PERFORMANCE OF WORK) 55.0 Execution of Work 56.0 Co-ordination and Inspection of work 57.0 Work in Monsoon & Dewatering 58.0 Work on Sundays & Holidays 59.0 General Conditions for construction & Erection Work 60.0 Alterations in specification, Design & Extra Work 61.0 Drawings to be supplied by the Employer 62.0 Drawings to be supplied by the Contractor 63.0 Setting out works 64.0 Responsibility for Levels and Alignment 65.0 Materials to be supplied by contractor 66.0 Stores supplied by Employer 67.0 Conditions for issue of material 68.0 Materials Procured with assistance of Employer/Return of surplus 69.0 Materials obtained from dismantling 70.0 Articles of Value found 71.0 Discrepancies between instructions 72.0 Action where no specification is issued 73.0 Inspection of Works 74.0 Tests for Quality of Works 75.0 Samples for approval 76.0 Action and Compensation in case of bad work 77.0 Suspension of Work 78.0 Employer may do part of work 79.0 Possession prior to completion 80.0 Twelve months period of liability from the date of issue of completion certificate 80.3 Limitation of Liability 81.0 Care of Works 81.1 Defects prior to taking over 81.2 Defects after taking over 82.0 Guarantee/Transfer of Guarantee 83.0 Training of Employer's personnel 84.0 Replacement of Defective parts & materials 85.0 Indemnity 86.0 Construction Aids, Equipments, Tools & Tackles VOLUME I OF II (Sign & Seal of Bidder) Page 86 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 SECTION-VI (CERTIFICATES AND PAYMENTS) 87.0 Schedule of Rates and Payments i) Contractor's Remuneration ii) Schedule of Rates to be inclusive iii) Schedule of Rates to cover construction equipment, materials, labour etc. iv) Schedule of Rates to cover Royalties, Rents and claims. v) Schedule of Rates to cover taxes & duties vi) Schedule of Rates to cover risks of delay vii) Schedule of Rates cannot be altered 88.0 Procedure for Measurement and billing of works in progress 88.1 Billing Procedure 88.2 Secured Advance on materials 88.3 Dispute in mode of measurement 88.4 Rounding of Amounts 89.0 Lumpsum in Tender 90.0 Running Account Payments to be regarded as advances 91.0 Notices of Claims for Additional Payments 92.0 Payment of Contractor's bills 93.0 Receipt for Payment 94.0 Completion Certificate 94.1 Application for Completion Certificate 94.2 Completion Certificate 94.3 Completion Certificate Documents 95.0 Final Decision & Final Certificate 96.0 Certificate and Payments No evidence of completion 97.0 Deduction from Contract Price SECTION-VII (TAXES AND INSURANCE) 98.0 Taxes, Duties, Octroi etc. 99.0 Sales Tax/Turnover Tax 100.0 Statutory Variations 101.0 Insurance 101.1 General i) Employees State Insurance Act ii) Workmen Compensation and Employee's Liability Insurance iii) Accident or injury to workmen iv) Transit Insurance v) Automobile vi) General Liability vii) Any other Insurance required under law or regulations by Employer 102.0 Damage to Property or to any Person or any Third Party SECTION-VIII (LABOUR LAWS) 103.0 Labour laws 104.0 Implementation of Apprentices Act 1961 VOLUME I OF II (Sign & Seal of Bidder) Page 87 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 105.0 Contractor to indemnify the Employer 106.0 Health and Sanitary Arrangement for worker SECTION-IX (APPLICABLE LAWS AND SETTLEMENT OF DISPUTES) 107.0 Arbitration 108.0 Jurisdiction SECTION-X (SAFETY CODES) 109.0 General 110.0 Safety Regulations 111.0 First Aid and Industrial Injuries 112.0 General Rules 113.0 Contractor's barricades 114.0 Scaffolding 115.0 Excavation and Trenching 116.0 Demolition/General Safety 117.0 Care in Handling Inflammable Gas 118.0 Temporary Combustible Structures 119.0 Precautions against Fire 120.0 Explosives 121.0 Mines Act 122.0 Preservation of Places 123.0 Outbreak of Infectious diseases 124.0 Use of intoxicants VOLUME I OF II (Sign & Seal of Bidder) Page 88 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Section- I. Definitions 1. Definition of Terms: Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 General Conditions of Contract VOLUME I OF II 1.1 In this CONTRACT (as here-in-after defined) the following words andexpressions shall have the meanings hereby assigned to them except where the context otherwise required. 1.1.1 The EMPLOYER/COMPANY/BGL means Bhagyanagar Gas Limited incorporated under the Company‟s act 1956 and having its registered office at Parishram Bhawan, APIDC Building, Basheer Bagh, Hyderabad-500004 and includes its successors and assigns. 1.1.2 The "CONTRACTOR" means the person or the persons, firm or Company or corporation whose tender has been accepted by the EMPLOYER and includes the CONTRACTOR's legal Representatives his successors and permitted assigns. 1.1.3 The ENGINEER/ENGINEER-IN-CHARGE" shall mean the person designated from time to time by the BGL and shall include those who are expressly authorized by him to act for and on his behalf for operation of this CONTRACT. 1.1.4 The "WORK" shall mean and include all items and things to be supplied/ done and services and activities to be performed by the CONTRACTOR in pursuant to and in accordance with CONTRACT or part thereof as the case may be and shall include all extra, additional, altered or substituted works as required for purpose of the CONTRACT. 1.1.5 The "PERMANENT WORK" means and includes works which will be incorporated in and form a part of the work to be handed over to the EMPLOYER by the CONTRACTOR on completion of the CONTRACT. 1.1.6 "CONSTRUCTION EQUIPMENT" means all appliances/equipment and things whatsoever nature for the use in or for the execution, completion, operation, or maintenance of the work or temporary works (as hereinafter defined) but does not include materials or other things intended to form or to be incorporated into the WORK, or camping facilities. 1.1.7 "CONTRACT DOCUMENTS" means collectively the Tender Documents, Designs, Drawings, Specification, Schedule of Quantities and Rates, Letter of Acceptance and agreed variations if any, and such other documents constituting the tender and acceptance thereof. 1.1.7 CONSULTANT: means ------------------------------- who are the consulting engineer to the Employer for this project and having registered office at -------- ---------------------- ------------------------------------------------------------------------------------------------------- (Sign & Seal of Bidder) Page 89 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 1.1.9 The "SUB-CONTRACTOR" means any person or firm or Company (other than the CONTRACTOR) to whom any part of the work has been entrusted by the CONTRACTOR, with the written consent of the ENGINEER-IN-CHARGE, and the legal representatives, successors and permitted assigns of such person, firm or company. 1.1.10 The "CONTRACT” shall mean the Agreement between the EMPLOYER and the CONTRACTOR for the execution of the works including therein all contract documents. 1.1.11 The "SPECIFICATION" shall mean all directions the various technical specifications, provisions attached and referred to the Tender Documents which pertain to the method and manner of performing the work or works to the quantities and qualities of the work or works and the materials to be furnished under the CONTRACT for the work or works, as may be amplified or modified by the BGL or ENGINEER-IN- CHARGE during the performance of CONTRACT in order to provide the unforeseen conditions or in the best interests of the work or works. It shall also include the latest edition of relevant Standard Specifications including all addenda/corrigenda published before entering into CONTRACT. 1.1.12 The "DRAWINGS" shall include maps, plans and tracings or prints or sketches thereof with any modifications approved in writing by the ENGINEER- IN-CHARGE and such other drawing as may, from time to time, be furnished or approved in writing by the ENGINEER-IN-CHARGE. 1.1.13 The "TENDER" means the proposal along with supporting documents submitted by the CONTRACTOR for consideration by the EMPLOYER. 1.1.14 The "CHANGE ORDER" means an order given in writing by the ENGINEER-IN- CHARGE to effect additions to or deletion from and alteration in the works. 1.1.15 The "COMPLETION CERTIFICATE" shall mean the certificate to be issued by the ENGINEER-IN-CHARGE when the works have been completed entirely in accordance with CONTRACT DOCUMENT to his satisfaction. 1.1.16 The "FINAL CERTIFICATE" in relation to a work means the certificate regarding the satisfactory compliance of various provision of the CONTRACT by the CONTRACTOR issued by the ENGINEER-INCHARGE/ EMPLOYER after the period of liability is over. 1.1.17 “DEFECT LIABILITY PERIOD” in relation to a work means the specified period from the date of COMPLETION CERTIFICATE upto the date of issue of FINAL CERTIFICATE during which the CONTRACTOR stands responsible for rectifying all defects that may appear in the works executed by the CONTRACTOR in pursuance of the CONTRACT and includes warranties against Manufacturing/Fabrication/ Erection/Construction defects covering all materials plants, equipment, components, and the like supplied by the CONTRACTOR, works executed against workmanship defects. (Sign & Seal of Bidder) Page 90 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 1.1.18 The "APPOINTING AUTHORITY" for the purpose of arbitration shall be the CHAIRMAN and MANAGING DIRECTOR or any other person so designated by the EMPLOYER. 1.1.19 "TEMPORARY WORKS" shall mean all temporary works of every kind required in or about the execution, completion or maintenance of works. 1.1.20"PLANS" shall mean all maps, sketches and layouts as are incorporated in the CONTRACT in order to define broadly the scope and specifications of the work or works, and all reproductions thereof. 1.1.21 "SITE" shall mean the lands and other places on, under, in or through which the permanent works are to be carried out and any other lands or places provided by the EMPLOYER for the purpose of the CONTRACT. 1.1.22 "NOTICE IN WRITING OR WRITTEN NOTICE" shall mean a notice in written, typed or printed characters sent (unless delivered personally or otherwise proved to have been received by the addressee) by registered post to the latest known private or business address or registered office of the addressee and shall be deemed to have been received in the ordinary course of post it would have been delivered. 1.1.23 "APPROVED" shall mean approved in writing including subsequent written confirmation of previous verbal approval and "APPROVAL" means approval in writing including as aforesaid. 1.1.24 "LETTER OF INTENT/FAX OF INTENT” shall mean intimation by a Fax/Letter to Tenderer(s) that the tender has been accepted in accordance with the provisions contained in the letter. 1.1.25 "DAY" means a day of 24 hours from midnight to midnight irrespective of the number of hours worked in that day. 1.1.26 "WORKING DAY" means any day which is not declared to be holiday or rest day by the EMPLOYER. 1.1.27 "WEEK" means a period of any consecutive seven days. 1.1.28"METRIC SYSTEM" - All technical documents regarding the construction of works are given in the metric system and all work in the project should be carried out according to the metric system. All documents concerning the work shall also be maintained in the metric system. 1.1.29 "VALUE OF CONTRACT” or “TOTAL CONTRACT PRICE” shall mean the sum accepted or the sum calculated in accordance with the prices accepted in tender and/or the CONTRACT rates as payable to the CONTRACTOR for the entire execution and full completion of the work, including change order. (Sign & Seal of Bidder) Page 91 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 1.1.30 "LANGUAGE FOR DRAWINGS AND INSTRUCTION" All the drawings, titles, notes, instruction, dimensions, etc. shall be in English Language. 1.1.31"MOBILIZATION" shall mean establishment of sufficiently adequate infrastructure by the CONTRACTOR at "SITE" comprising of construction equipments, aids, tools tackles including setting of site offices with facilities such as power, water, communication etc. establishing manpower organisation comprising of Resident Engineers, Supervising personnel and an adequate strength of skilled, semi-skilled and un-skilled workers, who with the so established infrastructure shall be in a position to commence execution ofwork at site(s), in accordance with the agreed Time Schedule of Completion of Work. "MOBILISATION" shall be considered to have been achieved, if the CONTRACTOR is able to establish infrastructure as per Time Schedule, where so warranted in accordance with agreed schedule of work implementation to the satisfaction of ENGINEER-IN-CHARGE/ EMPLOYER. 1.1.32 "COMMISSIONING" shall mean pressing into service of the system including the plant(s), equipment(s), vessel(s), pipeline, machinery(ies), or anyother section or sub- section of installation(s) pertaining to the work of the CONTRACTOR after successful testing and trial runs of the same. • "COMMISSIONING" can be either for a completed system or a part of system of a combination of systems or sub-systems and can be performed in any sequence as desired by EMPLOYER and in a manner established to be made suited according to availability of pre-requisites. Any such readjustments made by EMPLOYER in performance of"COMMISSIONING" activity will not be construed to be violating CONTRACT provisions and CONTRACTOR shall be deemed to have provided for the same. Section-II General Information 2. General Information 2.1 a) Location of Site: The proposed location of Project site is defined in the Special Conditions of Contract. b) Access by Road: CONTRACTOR, if necessary, shall build other temporary access roads to the actual site of construction for his own work at his own cost. The CONTRACTOR shall be required to permit the use of the roads so constructed by him for vehicles of any other parties who may be engaged on the project site. The CONTRACTOR shall also facilitate the construction ofthe permanent roads should the construction there of start while he is engaged on this work. He shall make allowance in his tender for any inconvenience he anticipates on such account. Non-availability of access roads, railway siding and railway wagons for the use of the CONTRACTOR shall in no case condone any delay in the execution of WORK nor be the cause for any claim for compensation against the EMPLOYER. 2.2 Scope of Work: The scope of WORK is defined in the Technical Part of the tender document. The CONTRACTOR shall provide all necessary materials, equipment, (Sign & Seal of Bidder) Page 92 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II labour etc. for the execution and maintenance of the WORK till completion unless otherwise mentioned in the Tender Document. 2.3 Water Supply: Contractor will have to make his own arrangements for supply of water to his labour camps and for works. All pumping installations, pipe net work and distribution system will have to be carried out by the Contractor at his own risk and cost. Alternatively the Employer at his discretion may endeavor to provide water to the Contractor at the Employer's source of supply provided the Contractor makes his own arrangement for the water meter which shall be in custody of the Employer and other pipe net works from source of supply and such distribution pipe network shall have prior approval of the Engineer-in-Charge so as not to interfere with the layout and progress of the other construction works. In such case, the rate for water shall be deducted from the running account bills. However, the Employer does not guarantee the supply of water and this does not relieve the Contractor of his responsibility in making his own arrangement and for the timely completion of the various works as stipulated. 2.4 Power Supply: 2.4.1 Subject to availability, EMPLOYER will supply power at 400/440 V at only one point at the nearest sub-station, from where the CONTRACTOR will make his own arrangement for temporary distribution. The point of supply will not be more than 500 m away from the CONTRACTOR'S premises. All the works will be done as per the applicable regulations and passed by the ENGINEER-IN-CHARGE. The temporary line will be removed forthwith after the completion of work or if there is any hindrance caused to the other works due to the alignment of these lines, the CONTRACTOR will re-route or remove the temporary lines at his own cost. The CONTRACTOR at his cost will also provide suitable electric meters, fuses, switches, etc. for purposes of payment to the EMPLOYER which should be in the custody and control of the EMPLOYER. The cost of power supply shall be payable to the EMPLOYER every month for Construction Works power which would be deducted from the running account bills. The EMPLOYER shall not, however, guarantee the supply of electricity nor have any liability in respect thereof. No claim for compensation for any failure or short supply of electricity will be admissible. 2.4.2 It shall be the responsibility of the CONTRACTOR to provide and maintain the complete installation on the load side of the supply with due regard to safety requirement at site. All cabling, equipment, installations etc. Shall comply in all respects with the latest statutory requirements and safety provisions i.e., as per the Central/State Electricity Acts and Rules etc. The CONTRACTOR will ensure that his equipment and Electrical Wiring etc., are installed, modified, maintained by a licensed Electrician/Supervisor. A test certificate is to be produced to the ENGINEER-IN-CHARGE for his approval, before power is made available. 2.4.3 At all times, IEA regulations shall be followed failing which the EMPLOYER has a right to disconnect the power supply without any reference to the CONTRACTOR. No claim shall be entertained for such disconnection by the ENGINEER-IN- (Sign & Seal of Bidder) Page 93 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II CHARGE. Power supply will be reconnected only after production of fresh certificate from authorized electrical supervisors. 2.4.4 The EMPLOYER is not liable for any loss or damage to the CONTRACTOR's equipment as a result of variation in voltage or frequency or interruption in power supply or other loss to the CONTRACTOR arising therefrom. 2.4.5 The CONTRACTOR shall ensure that the Electrical equipment installed by him is such that average power factors do not fall below 0.90 at his premises. In case power factor falls below 0.90 in any month, he will reimburse to the EMPLOYER at the penal rate determined by the EMPLOYER for all units consumed during the month. 2.4.6 The power supply required for CONTRACTOR's colony near the plant site will be determined by the EMPLOYER and shall be as per State Electricity Board's Rules and other statutory provisions applicable for such installations from time to time. In case of power supply to CONTRACTOR's colony, the power will be made available at a single point and the CONTRACTOR shall make his own arrangement at his own cost for distribution to the occupants of the colony as per Electricity Rules and Acts. The site and colony shall be sufficiently illuminated to avoid accidents. 2.4.7 The CONTRACTOR will have to provide and install his own lights and power meters which will be governed as per Central/State Government Electricity Rules. The meters shall be sealed by the EMPLOYER. 2.4.8 In case of damage of any of the EMPLOYER‟s equipment on account of fault, intentional or unintentional on the part of the CONTRACTOR, the EMPLOYER reserves the right to recover the cost of such damage from the CONTRACTOR's bill. Cost of HRC Fuses replaced at the EMPLOYER's terminals due to any fault in the CONTRACTOR's installation shall be to CONTRACTOR's account at the rates decided by the ENGINEER-IN-CHARGE. 2.4.9 Only motors upto 3 HP will be allowed to be started direct on line. For motors above 3 HP and upto 100 HP a suitable Starting device approved by the ENGINEER- IN- CHARGE shall be provided by the CONTRACTOR. For motors above 100 HP slipring induction motors with suitable starting devices as approved by the ENGINEER- IN-CHARGE shall be provided by the CONTRACTOR. 2.4.10The CONTRACTOR shall ensure at his cost that all electrical lines and equipment and all installations are approved by the State Electricity Inspector before power can be supplied to the EMPLOYER. 2.4.11The total requirement of power shall be indicated by the tenderer alongwith his tender. 2.5 Land for Contractor‟s Field Office, Godown and Workshop: The EMPLOYER will, at his own discretion and convenience and for the duration of the execution of the work make available near the site, land for construction of CONTRACTOR's Temporary Field Office, godowns workshops and assembly yard required for the execution of the CONTRACT. The CONTRACTOR shall at his own cost construct (Sign & Seal of Bidder) Page 94 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II all these temporary buildings and provide suitable water supply and sanitary arrangement and get the same approved by the ENGINEER-IN-CHARGE On completion of the works undertaken by the CONTRACTOR, he shall remove all temporary works erected by him and have the SITE cleaned as directed by ENGINEER-IN-CHARGE. If the CONTRACTOR shall fail to comply with these requirements, the ENGINEER-IN-CHARGE may at the expenses of the CONTRACTOR remove such surplus, and rubbish materials and dispose off the same as he deems fit and get the site cleared as aforesaid; and CONTRACTOR shall forthwith pay the amount of all expenses so incurred and shall have no claim in respect of any such surplus materials disposed off as aforesaid. But the EMPLOYER reserves the right to ask the CONTRACTOR any time during the pendency of the CONTRACT to vacate the land by giving 7 days notice on security reasons or on national interest or otherwise. Rent may be charged for the land so occupied from contractor by the Employer. The CONTRACTOR shall put up temporary structures as required by them for their office, fabrication shop and construction stores only in the area allocated to them on the project site by the EMPLOYER or his authorised representative. No tea stalls/canteens should be put up or allowed to be put up by any CONTRACTOR in the allotted land or complex area without written permission of the EMPLOYER. No unauthorised buildings, constructions or structures should be put up by the CONTRACTOR anywhere on the project site. For uninterrupted fabrication work, the CONTRACTOR shall put up temporary covered structures at his cost within Area in the location allocated to them in the project site by the EMPLOYER or his authorised representative. No person except for authorised watchman shall be allowed to stay in the plant area/CONTRACTOR's area after completion of the day's job without prior written permission from ENGINEER-IN-CHARGE. 5.6 Land for Residential Accommodation:-:No Land shall be made available for residential accommodation for staff and labour of CONTRACTOR. Section-III. General Instructions to Tenderers 3. Submission of Tender: 3.1 TENDER must be submitted without making any additions, alterations, and as per details given in other clauses hereunder. The requisite details shall be filled in by the TENDERER at space provided under “Submission of Tender at the beginning of GCC of Tender Document. The rate shall be filled only in the schedule given in this Tender Document. 3.2 Addenda/Corrigenda to this Tender Document, if issued, must be signed, submitted along with the Tender Document. The tenderer should write clearly the revised quantities in Schedule of Rates of Tender Document and should price the WORK based on revised quantities when amendments of quantities are issued in addenda. 3.3 Covering letter alongwith its enclosures accompanying the Tender Document and all further correspondence shall be submitted in duplicate. (Sign & Seal of Bidder) Page 95 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 3.4 Tenderers are advised to submit quotations based strictly on the terms and conditions and specifications contained in the Tender Documents and not to stipulate any deviations. 3.5 Tenders should always be placed in double sealed covers, super scribing ["QUOTATION DO NOT OPEN" Tender for _________________________ Project of Bhagyanagar Gas Limited due for opening on _______________________]. The Full Name, Address and Telegraphic Address, Fax No. of the Tenderers shall be written on the bottom left hand corner of the sealed cover. 4. Documents: 4.1 General: The tenders as submitted, will consist of the following: i) Complete set of Tender Documents (Original) as sold duly filled in and signed by the tenderer as prescribed in different clauses of the Tender Documents. ii) Earnest money in the manner specified in Clause 6 hereof. iii) Power of Attorney or a true copy thereof duly attested by a Gazetted Officer in case an authorised representative has signed the tender, as required by Clause 14 hereof. iv) Information regarding tenderers in the proforma enclosed. v) Details of work of similar type and magnitude carried out by the Tenderer in the proforma provided in the tender document. vi) Organisation chart giving details of field management at site, the tenderer proposes to have for this job. vii) Details of construction plant and equipments available with the tenderer for using in this work. viii) Solvency Certificate from Scheduled Bank to prove the financial ability to carry out the work tendered for. ix) Latest Balance Sheet and Profit & Loss Account duly audited. x) Details of present commitment as per proforma enclosed to tender. xi) Data required regarding SUB-CONTRACTOR(s)/ Supplier/ Manufacturers and other technical information the tenderer wish to furnish. xii) Provident fund registration certificate xiii) List showing all enclosures to tender. 4.2 All pages are to be Initiated: All signatures in Tender Documents shall be dated, as well as, all the pages of all sections of Tender Documents shall be initialed at the lower right hand corner and signed wherever required in the tender papers by the TENDERER or by a person holding power of attorney authorising him to sign on behalf of the tenderer before submission of tender. 4.3 Rates to be in Figures and Words: The tender should quote in English both in figures as well as in words the rates and amounts tendered by him in the Schedule of Rates of Tender submitted by the CONTRACTOR for each item and in such a way that interpolation is not possible. The amount for each item should be worked out and entered and requisite total given of all items, both in figures and in words. The tendered amount for the work shall be entered in the tender and duly signed by the Tenderer. (Sign & Seal of Bidder) Page 96 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II If some discrepancies are found between the RATES in FIGURES and WORDS or the AMOUNT shown in the tender, the following procedure shall be followed: a) When there is difference between the rates in figures and words, the rate which corresponds to the amount worked out by the tenderer shall be taken as correct. b) When the rate quoted by the tenderer in figures and words tally but the amount is incorrect the rate quoted by the tenderer shall be taken as correct. c) When it is not possible to ascertain the correct rate by either of above methods, the rate quoted in words shall be taken as correct. 4.4 Corrections and Erasures: All correction(s) and alteration(s) in the entries of tender paper shall be signed in full by the TENDERER with date. No erasure or over writing is permissible. 4.5 Signature of Tenderer: 4.5.1 The TENDERER shall contain the name, residence and place of business of person or persons making the tender and shall be signed by the TENDERER with his usual signature. Partnership firms shall furnish the full names of all partners in the tender. It should be signed in the partnership's name by all the partners or by duly authorised representatives followed by the name and designation of the person signing. Tender by a corporation shall be signed by an authorised representative, and a Power of Attorney in that behalf shall accompany the tender. A copy of the constitution of the firm with names of all partners shall be furnished. 4.5.2 When a tenderer signs a tender in a language other than English, the total amount tendered should, in addition, be written in the same language. The signature should be attested by at least one witness. 4.6 Witness: Witness and sureties shall be persons of status and property and their names, occupation and address shall be stated below their signature. 4.7 Details of Experience: The tenderer should furnish, alongwith his tender, details of previous experience in having successfully completed in the recent past works of this nature, together with the names of Employers, location of sites and value of contract, date of commencement and completion of work, delays if any, reasons of delay and other details alongwith documentary evidence(s). 4.8 Liability of Government of India: It is expressly understood and agreed by and between Bidder or/Contractor and M/s Bhagyanagar Gas Limited, and that M/s Bhagyanagar Gas Limited, is entering into this agreement solely on its own behalf and not on behalf of any other person or entity. In particular, it is expressly understood and agreed that the Government of India is not a party to this agreement and has no liabilities, obligations or rights hereunder. It is expressly understood and agreed that M/ Bhagyanagar Gas Limited. is an independent legal entity with power and authority to enter into contracts solely on its own behalf under the applicable Laws of India and general principles of Contract Law. The Bidder/Contractor expressly agrees, acknowledges and understands that M/s Bhagyanagar Gas Limited. is not an agent, (Sign & Seal of Bidder) Page 97 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II representative or delegate of the Government of India. It is further understood and agreed that the Government of India is not and shall not be liable for any acts, omissions, commissions, breaches or other wrongs arising out of the contract. Accordingly, Bidder/Contractor hereby expressly waives, releases and foregoes any and all actions or claims, including cross claims, impleader claims or counter claims against the Government of India arising out of this contract and covenants not to sue to Government of India as to any manner, claim, cause of action or thing whatsoever arising of or under this agreement. 5. Transfer of Tender Documents: 5.1 Transfer of Tender Documents purchased by one intending tenderer to another is not permissible. 6. Earnest Money: 6.1 The bidder must pay Earnest Money as given in the letter /notice inviting tenders and attach the official receipt with the tender failing which the tender is liable to be rejected and representatives of such tenderers will not be allowed to attend the tender opening. Earnest Money can be paid in Demand Drafts or Bank Guarantee or Banker‟s Cheque or Letter of Credit from any Indian scheduled bank or a branch of an International bank situated in India and registered with Reserve Bank of India as scheduled foreign bank. However, other than the Nationalised Indian Banks, the banks whose BGs are furnished, must be commercial banks having net worth in excess of Rs. 100 crores and a declaration to this effect should be made by such commercial bank either in the bank guarantee itself or separately on a letter head. The bid guarantee shall be submitted in the prescribed format. Note: The Bank Guarantee so furnished by the tenderer shall be in the proforma prescribed by the EMPLOYER. No interest shall be paid by the EMPLOYER on the Earnest Money deposited by the tenderer. The Bank Guarantee furnished in lieu of Earnest Money shall be kept valid for a period of "SIX MONTHS" from the date of opening of tender.(TWO MONTHS beyond the bid due date). The Earnest Money deposited by successful tenderer shall be forfeited if the Contractor fails to furnish the requisite Contract Performance Security as per clause 24 hereof and /or fails to start work within a period of 15 days or fails to execute the AGREEMENT within 15 days of the receipt by him of the Notification of Acceptance of Tender. Note: The Earnest Money of the unsuccessful bidder will be returned by EMPLOYER/CONSULTANT, directly to the tenderer (s), within a reasonable period of time but not later than 30 days after the expiration of the period of bid validity prescribed by EMPLOYER. 7 Validity: 7.1 Tender submitted by tenderers shall remain valid for acceptance for a period of "3 MONTHS" from the date of opening of the tender. The tenderers shall not be entitled during the said period of 3 months, without the consent in writing of the EMPLOYER, to revoke or cancel his tender or to vary the tender given or any term thereof. In case of tender revoking or canceling his tender or varying any term in (Sign & Seal of Bidder) Page 98 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II regard thereof without the consent of EMPLOYER in writing, the EMPLOYER shall forfeit Earnest Money paid by him alongwith tender. 8 Addenda/Corrigenda 8.1 Addenda/ Corrigenda to the Tender Documents will be issued in duplicate prior to the date of opening of the tenders to clarify documents or to reflect modification in design or CONTRACT terms. 8.2 Each addenda/ corrigendum issued will be issued in duplicate to each person or organisation to whom set of Tender Documents has been issued. Recipient will retain tenderer's copy of each Addendum/Corrigendum and attach original copy duly signed along with his offer. All Addenda/Corrigenda issued shall become part of Tender Documents. 9 Right of Employer to Accept or Reject Tender: 9.1 The right to accept the tender will rest with the EMPLOYER. The EMPLOYER, however, does not bind himself to accept the lowest tender, and reserves to itself the authority to reject any or all the tenders received without assigning any reason whatsoever. At the option of the Employer, the work for which the tender had been invited, may be awarded to one Contractor or split between more than one bidders, in which case the award will be made for only that part of the work, in respect of which the bid has been accepted. The quoted rates should hold good for such eventualities.Tenders in which any of the particulars and prescribed information are missing or are incomplete in any respect and/or the prescribed conditions are not fulfilled are liable to be rejected. The Tender containing uncalled for remarks or any additional conditions are liable to be rejected. Canvassing in connection with tenders is strictly prohibited and tenders submitted by the Tenderers who resort to canvassing will be liable to rejection. 10 Time Schedule 10.1 The WORK shall be executed strictly as per the TIME SCHEDULE specified in TENDER/CONTRACT Document. The period of construction given in Time Schedule includes the time required for mobilisation as well as testing, rectifications if any, retesting and completion in all respects to the entire satisfaction of the ENGINEER-IN- CHARGE. 10.2 A joint programme of execution of the WORK will be prepared by the ENGINEER- IN-CHARGE and CONTRACTOR based on priority requirement of this project. This programme will take into account the time of completion mentioned in 10.1 above and the time allowed for the priority works by the ENGINEER-IN-CHARGE. 10.3 Monthly/Weekly construction programme will; be drawn up by the ENGINEER-IN- CHARGE jointly with the CONTRACTOR, based on availability of work fronts and the joint construction programme as per 10.2 above. The CONTRACTOR shall scrupulously adhere to these targets /programmes by deploying adequate personnel, construction tools and tackles and he shall also supply himself all materials of his scope of supply in good time to achieve the targets/programmes. In all matters concerning the extent of targets set out in the weekly and monthly programmes and the degree of achievements the decision of the ENGINEER-IN-CHARGE will be final and binding on the CONTRACTOR. (Sign & Seal of Bidder) Page 99 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED 11 Tenderer‟s Responsibility Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 11.1 The intending tenderers shall be deemed to have visited the SITE and familiarised submitting the tender. Non-familiarity with the site conditions will not be considered a reason either for extra claims or for not carrying out the works in strict conformity with the DRAWINGS and SPECIFICATIONS or for any delay in performance. 12 Retired Government or Company Officers 12.1 No Engineer of Gazetted rank or other Gazetted Officer employed in Engineering or Administrative duties in an Engineering Department of the States/ Central Government or of the EMPLOYER is allowed to work as a CONTRACTOR for a period of two years after his retirement from Government Service, or from the employment of the EMPLOYER without the previous permission of the EMPLOYER. The CONTRACT, if awarded, is liable to be cancelled if either the CONTRACTOR or any of his employees is found at any time to be such a person, who has not obtained the permission of the State/Central Government or of the EMPLOYER as aforesaid before submission of tender, or engagement in the CONTRACTOR'S service as the case may be. 13 Signing of the Contract: 13.1 The successful tenderer shall be required to execute an AGREEMENT in the proforma attached with TENDER DOCUMENT within 15 days of the receipt by him of the Notification of Acceptance of Tender. In the event of failure on the part of the successful tenderer to sign the AGREEMENT within the above stipulated period, the Earnest Money or his initial deposit will be forefeited and the acceptance of the tender shall be considered as cancelled. 14 Field Management & Controlling/Coordinating Authority: 14.1 The field management will be the responsibility of the ENGINEER-IN-CHARGE, who will be nominated by the EMPLOYER. The ENGINEER-IN-CHARGE may also authorise his representatives to assist in performing his duties and functions. 14.2 The ENGINEER-IN-CHARGE shall coordinate the works of various agencies engaged at site to ensure minimum disruption of work carried out by different agencies. It shall be the responsibility of the CONTRACTOR to plan and execute the work strictly in accordance with site instructions to avoid hindrance to the work being executed by other agencies. 15 Note to Schedule of Rates: 15.1 The Schedule of Rates should be read in conjunction with all the other sections of the tender. 15.2 The tenderer shall be deemed to have studied the DRAWINGS, SPECIFICATIONS and details of work to be done within TIME SCHEDULE and to have aquainted himself of the condition prevailing at site. 15.3 Rates must be filled in the Schedule of Rates of original Tender Documents. If quoted in separate typed sheets no variation in item description or specification shall be accepted. Any exceptions taken by the tenderer to the Schedule of Rates shall be brought out in the terms and conditions of the offer. (Sign & Seal of Bidder) Page 100 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 15.4 The quantities shown against the various items are only approximate. Any increase or decrease in the quantities shall not form the basis of alteration of the rates quoted and accepted. 15.5 The EMPLOYER reserves the right to interpolate the rates for such items of work falling between similar items of lower and higher magnitude. 16 Policy for Tenders Under Consideration: 16.1 Only Those Tenders which are complete in all respects and are strictly in accordance with the Terms and Conditions and Technical Specifications of Tender Document, shall be considered for evaluation. Such Tenders shall be deemed to be under consideration immediately after opening of Tender and until such time an official intimation of acceptance /rejection of Tender is made by BGL to the Bidder. 16.2 Zero Deviation: Bidders to note that this is a ZERO DEVIATION TENDER. BGL will appreciate submission of offer based on the terms and conditions in the enclosed General Conditions of Contract (GCC), Special Conditions of Contract (SCC), Instructions to Bidders (ITB), Scope of Work, technical specifications etc. to avoid wastage of time and money in seeking clarifications on technical/ commercial aspects of the offer. Bidder may note that no technical and commercial clarifications will be sought for after the receipt of the bids. In case of any deviation/nonconformity observed in the bid, it will be liable for rejection. 17 Award of Contract: 17.1 The Acceptance of Tender will be intimated to the successful Tenderer by BGL either by Telex/ Telegram/ Fax or by Letter or like means-defined as LETTER OF ACCEPTANCE OF TENDER. 17.2 BGL will be the sole judge in the matter of award of CONTRACT and the decision of BGL shall be final and binding. 18 Clarification of Tender Document: 18.1 The Tender is required to carefully examine the Technical Specifications, Conditions of Contract, Drawings and other details relating to WORK and given in Tender Document and fully inform himself as to all conditions andmatters which may in any way affect the WORK or the cost thereof. In case the Tenderer is in doubt about the completeness or correctness of any of the contents of the Tender Documents he should request in writing for an interpretation/clarification to BGL in triplicate. BGL will then issue interpretation/clarification to Tenderer in writing. Such clarifications and or interpretations shall form part of the Specifications and Documents and shall accompany the tender which shall be submitted by tenderer within time anddate as specified in invitations to tender. 18.2 Verbal clarification and information given by BGL or its employee(s) or its representatives shall not in any way be binding on BGL. 19 Local Conditions: 19.1 It will be imperative on each tenderer to inform himself of all local conditions and factors which may have any effect on the execution of WORK covered under the Tender Document. In their own interest, the tenderer are requested to familiarise themselves with the Indian Income Tax Act 1961, Indian Companies Act 1956, Indian Customs Act 1962 and other related Acts and Laws and Regulations of India with (Sign & Seal of Bidder) Page 101 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II their latest amendments, as applicable BGL shall not entertain any requests for clarifications from the tenderer regarding such local conditions. 19.2 It must be understood and agreed that such factors have properly been investigated and considered while submitting the tender. No claim for financial or any other adjustments to VALUE OF CONTRACT, on lack of clarity of such factors shall be entertained. 20 Abnormal Rates: 20.1 The tenderer is expected to quote rate for each item after careful analysis of cost involved for the performance of the completed item considering all specifications and Conditions of Contract. This will avoid loss of profit or gain in case of curtailment or change of specification for any item. In case it is noticed that the rates quoted by the tenderer for any item are unusually high or unusually low, it will be sufficient cause for the rejection of the tender unless the EMPLOYER is convinced about the reasonableness after scrutiny of the analysis for such rate(s) to be furnished by the tenderer (on demand). Section-IV. General Obligations 21 Priority of Contract Documents 21.1 Except if and the extent otherwise provided by the Contract, the provisions of the General Conditions of Contract and Special Conditions shall prevail over those of any other documents forming part of the CONTRACT. Several documents forming the CONTRACT are to be taken as mutually explanatory of one another, but in case of ambiguities or discrepancies the same shall be explained and adjusted by the ENGINEER-IN-CHARGE who shall thereupon issue to the Contractor instructions thereon and in such event, unless otherwise provided in the Contract, the priority of the documents forming the Contract shall be as follows: 1) The Contract Agreement; 2) The Letter of Acceptance; 3) The (Instructions to Bidders)ITB; 4) Special Conditions of Contract (SCC); 5) General Conditions of Contract (GCC) 6) Any other document forming part of the Contract. Works shown in the DRAWING but not mentioned in the SPECIFICATIONS OR described in the SPECIFICATIONS without being shown in the DRAWINGS shall nevertheless be deemed to be included in the same manner as if they had been specifically shown upon the DRAWINGS and described in the SPECIFICATIONS. 21.2 Headings and Marginal Notes: All headings and marginal notes to the clauses of these General Conditions of Contract or to the SPECIFICATIONS or to any other Tender Document are solely for the purpose of giving a concise indication and not a summary of the contents thereof, and they shall never be deemed to be part thereof or be used in the interpretation or construction thereof the CONTRACT. 21.3 Singular and Plural: In CONTRACT DOCUMENTS unless otherwise stated specifically, the singular shall include the plural and vice versa wherever the context so requires. (Sign & Seal of Bidder) Page 102 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 21.4 Interpretation: Words implying `Persons' shall include relevant `Corporate Companies / Registered Associations/ Body of Individuals/ Firm of Partnership' as the case may be. 22 Special Conditions of Contract: 22.1 Special Conditions of Contract shall be read in conjunction with the General Conditions of Contract, specification of Work, Drawings and any other documents forming part of this CONTRACT wherever the context so requires. 22.2 Notwithstanding the sub-division of the documents into these separate sections and volumes every part of each shall be deemed to be supplementary to and complementary of every other part and shall be read with and into the CONTRACT so far as it may be practicable to do so. 22.3 Where any portion of the General Condition of Contract is repugnant to or at variance with any provisions of the Special Conditions of Contract, unless a different intention appears the provisions of the Special Conditions of Contract shall be deemed to over- ride the provisions of the General Conditions of Contract and shall to the extent of such repugnancy, or variations, prevail. 22.4 Wherever it is mentioned in the specifications that the CONTRACTOR shall perform certain WORK or provide certain facilities, it is understood that the CONTRACTOR shall do so at his cost and the VALUE OF CONTRACT shall be deemed to have included cost of such performance and provisions, so mentioned. 22.5 The materials, design and workmanship shall satisfy the relevant INDIAN STANDARDS, the JOB SPECIFICATIONS contained herein and CODES referred to. Where the job specification stipulate requirements in addition to those contained in the standard codes and specifications, these additional requirements shall also be satisfied. 23 Contractor to obtain his own Information: 23.1 The CONTRACTOR in fixing his rate shall for all purpose whatsoever reason may be, deemed to have himself independently obtained all necessary information for the purpose of preparing his tender and his tender as accepted shall be deemed to have taken into account all contingencies as may arise due to such information or lack of same. The correctness of the details, given in the Tender Document to help the CONTRACTOR to make up the tender is not guaranteed. The CONTRACTOR shall be deemed to have examined the CONTRACT DOCUMENTS, to have generally obtained his own information in all matters whatsoever that might affect the carrying out of the works at the schedules rates and to have satisfied himself to the sufficiency of his tender. Any error in description of quantity or omission there from shall not vitiate the CONTRACT or release the CONTRACTOR from executing the work comprised in the CONTRACT according to DRAWINGS and SPECIFICATIONS at the scheduled rates. He is deemed to have known the scope, nature and magnitude of the WORKS and the requirements of materials and labour involved etc., and as to what all works he has to complete in accordance with the CONTRACT documents whatever be the defects, omissions or errors that may be found in the DOCUMENTS. The CONTRACTOR shall be deemed to have visited surroundings, to have satisfied himself to the nature of all existing structures, if any, and also as to the nature and the conditions of the Railways, Roads, Bridges and Culverts, means of transport and communication, whether by land, water or air, and as topossible interruptions thereto (Sign & Seal of Bidder) Page 103 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II and the access and egress from the site, to have made enquiries, examined and satisfied himself as to the sites for obtaining sand, stones, bricks and other materials, the sites for disposal of surplus materials, the available accommodation as to whatever required, depots and such other buildings as may be necessary for executing and completing the works, to have made local independent enquiries as to the sub-soil, subsoil water and variations thereof, storms, prevailing winds, climatic conditions and all other similar matters effecting these works. He is deemed to have acquainted himself as to his liability of payment of Government Taxes, Customs duty and other charges, levies etc. Any neglect or omission or failure on the part of the CONTRACTOR in obtaining necessary and reliable information upon the foregoing or any other matters affecting the CONTRACT shall not relieve him from any risks or liabilities or the entire responsibility from completion of the works at the scheduled rates and times in strict accordance with the CONTRACT. It is, therefore, expected that should the CONTRACTOR have any doubt as to the meaning of any portion of the CONTRACT DOCUMENT he shall set forth the particulars thereof in writing to EMPLOYER in duplicate, before submission of tender. The EMPLOYER may provide such clarification as may be necessary in writing to CONTRACT, such clarifications as provided by EMPLOYER shall form part of CONTRACT DOCUMENTS. No verbal agreement or inference from conversation with any effect or employee of the EMPLOYER before, during or after the execution of the CONTRACT agreement shall in any way affect or modify and of the terms or obligations herein contained. Any change in layout due to site conditions or technological requirement shall be binding on the CONTRACTOR and no extra claim on this account shall be entertained. 24 Contract Performance Security: 24.1 The CONTRACTOR shall furnish to the EMPLOYER, within 30 days from the date of notification of award, a security in the sum of 10% of the accepted value of the tender or the actual value of work to be done whichever is applicable due to any additional work or any other reasons, in the form of a Bank draft/Banker‟s cheque or Bank Guarantee or irrevocable Letter of credit (as per proforma enclosed) as Contract Performance Security with the EMPLOYER which will be refunded after the expiry of DEFECTS LIABILITY PERIOD. 24.2 CONTRACTOR can furnish the Contract Performance Security in the form of Demand Draft or through a Bank Guarantee or through an irrevocable Letter of Credit from any Indian scheduled bank other than co-operative bank or a branch of an International bank situated in India and registered with Reserve Bank of India as scheduled foreign bank. However, other than the Nationalised Indian Banks, the banks whose BGs are furnished, must be commercial banks having net worth in excess of Rs. 100 crores and a declaration to this effect should be made by such commercial bank either in the bank guarantee itself or separately on a letter head. The bank guarantee or the Letter of Credit shall be submitted in the prescribed format. 24.3 If the CONTRACTOR/SUB-CONTRACTOR or their employees or the CONTRACTOR‟s agents and representatives shall damage, break, deface or destroy any property belonging to the EMPLOYER or others during the execution of the CONTRACT, the same shall be made good by the CONTRACTOR at his own (Sign & Seal of Bidder) Page 104 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II expenses and in default thereof, the ENGINEER-IN-CHARGE may cause the same to be made good by other agencies and recover expenses from the CONTRACTOR (for which the certificate of the ENGINEER- IN-CHARGE shall be final). 24.4 All compensation or other sums of money payable by the CONTRACTOR to the EMPLOYER under terms of this CONTRACT may be deducted from or paid by the encashment or sale of a sufficient part of his Contract Performance Security or from any sums which may be due or may become due to the CONTRACTOR by the EMPLOYER of any account whatsoever and in the event of his Contract Performance Security being reduced by reasons of any such deductions or sale of aforesaid, the CONTRACTOR shall within ten days thereafter make good in cash, bank drafts as aforesaid any sum or sums which may have been deducted from or realised by sale of his Contract Performance Security, or any part thereof. No interest shall be payable by the EMPLOYER for sum deposited as Contract Performance Security. 24.5 Failure of the successful bidder to comply with the requirements of this Clause shall constitute sufficient grounds for the annulment of the award and the forfeiture of bid security. 25 Time of Performance: 25.1 Time for Mobilisation The work covered by this CONTRACT shall be commenced within fifteen (15) days, the date of letter/Fax of Intent and be completed in stages on or before the dates as mentioned in the TIME SCHEDULE OF COMPLETION OF WORK. The CONTRACTOR should bear in mind that time is the essence of this agreement. Request for revision of construction time after tenders are opened will not receive consideration. The above period of fifteen (15) days is included within the overall COMPLETION SCHEDULE, not over and above the completion time to any additional work or any other reasons. 25.2 Time Schedule of Construction: 25.2.1 The general Time Schedule of construction is given in the TENDER DOCUMENT. CONTRACTOR should prepare a detailed monthly or weekly construction program jointly with the ENGINEER-IN-CHARGE within 15 days of receipt of LETTER/FAX OF INTENT or ACCEPTANCE OF TENDER. The WORK shall be executed strictly as per the Time Schedule given in the CONTRACT DOCUMENT. The period of construction given includes the time required for mobilisation testing, rectifications, if any, retesting and completion in all respects in accordance with CONTRACT DOCUMENT to the entire satisfaction of the ENGINEER-IN- CHARGE. 25.2.2 The CONTRACTOR shall submit a detailed PERT network within the time frame agreed above consisting of adequate number of activities covering various key phases of the WORK such as design, procurement, manufacturing, shipment and field erection activities within fifteen (15) days from the date of LETTER/FAX OF INTENT. This network shall also indicate the interface facilities to be provided by the EMPLOYER and the dates by which such facilities are needed. 25.2.3 CONTRACTOR shall discuss the network so submitted with the EMPLOYER and the agreed network which may be in the form as submitted with the EMPLOYER or in revised form in line with the outcome of discussions shall form part of the CONTRACT, to be signed within fifteen (15) days from the date of LETTER OF (Sign & Seal of Bidder) Page 105 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II ACCEPTANCE OF TENDER. During the performance of the CONTRACT, if in the opinion of the EMPLOYER proper progress is not maintained suitable changes shall be made in the CONTRACTOR's operation to ensure proper progress. The above PERT network shall be reviewed periodically and reports shall be submitted by the CONTRACTOR as directed by EMPLOYER. 26 Force Majeure: 26.1 CONDITIONS FOR FORCE MAJEURES In the event of either party being rendered unable by Force Majeure to perform any obligations required to be performed by them under the CONTRACT the relative obligation of the party affected by such Force Majeure shall upon notification to the other party be suspended for the period during which Force Majeure event lasts. The cost and loss sustained by the either party shall be borne by the respective parties. The term "Force Majeure" as employed herein shall mean acts of God, earthquake, war (declared or undeclared), revolts, riots, fires, floods, rebellions, explosions, hurricane, sabotage, civil commotions and acts and regulations of respective Government of the two parties, namely the EMPLOYER and the CONTRACTOR. Upon the occurrence of such cause(s) and upon its termination, the party alleging that it has been rendered unable as aforesaid thereby, shall notify the other party in writing immediately but not later than 72 (Seventy-two) hours of the alleged beginning and ending thereof giving full particulars and satisfactory evidence in support of its claim. Time for performance of the relative obligation suspended by the ForceMajeures shall then stand extended by the period for which such cause lasts. If deliveries of bought out items and/or works to be executed by the CONTRACTOR are suspended by Force Majeure conditions lasting for more than 2 (two) months the EMPLOYER shall have the option to terminate the CONTRACT or re-negotiate the contract provisions. 26.2 OUTBREAK OF WAR 26.2.1 If during the currency of the CONTRACT there shall be an out-break of war whether declared or not, in that part of the World which whether financially or otherwise materially affect the execution of the WORK the CONTRACTOR shall unless and until the CONTRACT is terminated under the provisions in this clause continue to use his best endeavour to complete the execution of the WORK, provided always that the EMPLOYER shall be entitled, at any time after such out-break of war to terminate or re-negotiate the CONTRACT by giving notice in writing to the CONTRACTOR and upon such notice being given the CONTRACT shall, save as to the rights of the parties under this clause and to the operation of the clauses entitled settlement of Disputes and Arbitration hereof, be terminated but without prejudice to the right of either party in respect of any antecedent breach thereof. 26.2.2 If the CONTRACT shall be terminated under the provisions of the above clause, the CONTRACTOR shall with all reasonable diligence remove from the SITE all the CONTRACTOR's equipment and shall give similar facilities to his SUB- CONTRACTORS to do so. 27 Price reduction schedule: 27.1 Time is the essence of the CONTRACT. In case the CONTRACTOR fails to complete the WORK within the stipulated period, then, unless such failure is due to Force Majeure as defined in Clause 26 here above or due to EMPLOYER's defaults, (Sign & Seal of Bidder) Page 106 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II the Total Contract price shall be reduced by ½ % of the total Contract Price per complete week of delay or part thereof subject to a maximum of 5 % of the Total Contract Price,by way of reduction in price for delay and not as penalty. The said amount will be recovered from amount due to the Contractor/ Contractor‟s Contract Performance Security payable on demand. The decision of the ENGINEER-IN- CHARGE in regard to applicability of Price Reduction Schedule shall be final and binding on the CONTRACTOR. 27.2 All sums payable under this clause is the reduction in price due to delay in completion period at the above agreed rate. 27.3 BONUS FOR EARLY COMPLETION If the Contractor achieves completion of Works in all respect prior to the time schedule stipulated in the SCC, the Employer shall pay to the Contractor the relevant sum, if mentioned specifically in SCC, as bonus for early completion. The bonus for early completion, if provided specifically in SCC, shall be payable to the maximum ceiling of 2 ½ % of the total contract price. (*) Partial earlier completion may not always produce net benefits to the Employer, for example where utilization of the completed Works requires (a) the fulfillment of all parts of the Contract (e.g. the training of personnel); or (b) the completion of all Sections (e.g. in pipeline laying, where early completion of the laying of pipeline would not be useful if the compressor is still under installation); or (c) certain seasonal effects to take place (e.g. onset of the rainy season, for impounding a reservoir); or (d) other circumstances. Also a more rapid drawdown of budgeted funds may be required. All such factors should be considered prior to the inclusion of a bonus clause in the Contract. 28 Rights of the employer to forfeit contract performance security: 28.1 Whenever any claim against the CONTRACTOR for the payment of a sum of money arises out or under the CONTRACT, the EMPLOYER shall be entitled to recover such sum by appropriating in part or whole the Contract Performance Security of the CONTRACTOR. In the event of the security being insufficient or if no security has been taken from the CONTRACTOR, then the balance or the total sum recoverable, as the case may be shall be deducted from any sum then due or which at any time thereafter may become due to the CONTRACTOR. The CONTRACTOR shall pay to the EMPLOYER on demand any balance remaining due. 29 Failure by the contractor to comply with the provisions of the contract: 29.1 If the CONTRACTOR refuses or fails to execute the WORK or any separate part thereof with such diligence as will ensure its completion within the time specified in the CONTRACT or extension thereof or fails to perform any of his obligation under the CONTRACT or in any manner commits a breach of any of the provisions of the CONTRACT it shall be open to the EMPLOYER at its option by written notice to the CONTRACTOR: a) TO DETERMINE THE CONTRACT in which event the CONTRACT shall stand terminated and shall cease to be in force and effect on and from the date appointed by the EMPLOYER on that behalf, whereupon the CONTRACTOR shall stop forthwith any of the CONTRACTOR's work then in progress, except such WORK as the EMPLOYER may, in writing, require to be done to safeguard any property (Sign & Seal of Bidder) Page 107 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II or WORK, or installations from damage, and the EMPLOYER, for its part, may take over the work remaining unfinished by the CONTRACTOR and complete the same through a fresh contractor or by other means, at the risk and cost of the CONTRACTOR, and any of his sureties if any, shall be liable to the EMPLOYER for any excess cost occasioned by such work having to be so taken over and completed by the EMPLOYER over and above the cost at the rates specified in the schedule of quantities and rate/prices. b) WITHOUT DETERMINING THE CONTRACT to take over the work of the CONTRACTOR or any part thereof and complete the same through a fresh contractor or by other means at the risk and cost of the CONTRACTOR. The CONTRACTOR and any of his sureties are liable to the EMPLOYER for any excess cost over and above the cost at the rates specified in the Schedule of Quantities/ rates, occasioned by such works having been taken over and completed by the EMPLOYER. 29.2 In such events of Clause 29.1(a) or (b) above. a) The whole or part of the Contract Performance Security furnished by the CONTRACTOR is liable to be forfeited without prejudice to the right of the EMPLOYER to recover from the CONTRACTOR the excess cost referred to in the sub-clause aforesaid, the EMPLOYER shall also have the right of taking possession and utilising in completing the works or any part thereof, such as materials equipment and plants available at work site belonging to the CONTRACTOR as may be necessary and the CONTRACTOR shall not be entitled for any compensation for use or damage to such materials, equipment and plant. b) The amount that may have become due to the CONTRACTOR on account of work already executed by him shall not be payable to him until after the expiry of Six (6) calendar months reckoned from the date of termination of CONTRACT or from the taking over of the WORK or part thereof by the EMPLOYER as the case may be, during which period the responsibility for faulty materials or workmanship in respect of such work shall, under the CONTRACT, rest exclusively with the CONTRACTOR. This amount shall be subject to deduction of any amounts due from the CONTRACT to the EMPLOYER under the terms of the CONTRACT authorised or required to be reserved or retained by the EMPLOYER. 29.3 Before determining the CONTRACT as per Clause 29.1(a) or (b) provided in the judgement of the EMPLOYER, the default or defaults committed by the CONTRACTOR is/are curable and can be cured by the CONTRACTOR if an opportunity given to him, then the EMPLOYER may issue Notice in writing calling the CONTRACTOR to cure the default within such time specified in the Notice. 29.4 The EMPLOYER shall also have the right to proceed or take action as per 29.1(a) or (b) above, in the event that the CONTRACTOR becomes bankrupt, insolvent, compounds with his creditors, assigns the CONTRACT in favour of his creditors or any other person or persons, or being a company or a corporation goes into voluntary liquidation, provided that in the said events it shall not be necessary for the EMPLOYER to give any prior notice to the CONTRACTOR. (Sign & Seal of Bidder) Page 108 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 29.5 Termination of the CONTRACT as provided for in sub- clause 29.1(a) above shall not prejudice or affect their rights of the EMPLOYER which may have accrued upto the date of such termination. 30 Contractor remains liable to pay compensation if action not taken under clause 29: 30.1 In any case in which any of the powers conferred upon the EMPLOYER BY CLAUSE 29.0 thereof shall have become exercisable and the same had not been exercised, the non-exercise thereof shall not constitute a waiver of any of the conditions hereof and such powers shall notwithstanding be exercisable in .the event of any further case of default by the CONTRACTOR for which by any clause or clauses hereof he is declared liable to pay compensation amounting to the whole of his Contract Performance Security, and the liability of the CONTRACTOR for past and future compensation shall remain unaffected. In the event of the EMPLOYER putting in force the power under above sub-clause (a), (b) or (c) vested in him under the preceding clause he may, if he so desired, take possession of all or any tools, and plants, materials and stores in or upon the works or the site thereof belonging to the CONTRACTOR or procured by him and intended to be used for the execution of the WORK or any part thereof paying or allowing for the same in account at the CONTRACT rates or in case of these not being applicable at current market rates to be certified by the ENGINEER-IN-CHARGE whose certificate thereof shall be final, otherwise the ENGINEER-IN- CHARGE may give notice in writing to the CONTRACTOR or his clerk of the works, foreman or other authorised agent, requiring him to remove such tools, plant, materials or stores from the premises (within a time to be specified in such notice), and in the event of the CONTRACTOR failing to comply with any such requisition, the ENGINEER-IN-CHARGE may remove them at the CONTRACTOR's expense or sell them by auction or private sale on account of the CONTRACTOR and at his risk in all respects without any further notice as to the date, time or place of sale and the certificate of the ENGINEER-IN- CHARGE as to the expenses of any such removal and the amount of the proceeds and expenses of any such sale shall be final and conclusive against the CONTRACTOR. 31 Change in constitution: 31.1 Where the CONTRACTOR is a partnership firm, the prior approval of the EMPLOYER shall be obtained in writing, before any change is made in the constitution of the firm. Where the CONTRACTOR is an individual or a Hindu undivided family business concern, such approval as aforesaid shall,likewise be obtained before such CONTRACTOR enters into any agreement with other parties, where under, the reconstituted firm would have the right to carry out the work hereby undertaken by the CONTRACTOR. In either case if prior approval as aforesaid is not obtained, the CONTRACT shall be deemed to have been allotted in contravention of clause 37 hereof and the same action may be taken and the same consequence shall ensure as provided in the said clause. 32 Termination of contract 32(A) TERMINATION OF CONTRACT FOR DEATH: If the CONTRACTOR is an individual or a proprietary concern and the individual or the proprietor dies or if the CONTRACTOR is a partnership concern and one of the partner dies then unless, the EMPLOYER is satisfied that the legal representative of (Sign & Seal of Bidder) Page 109 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II the individual or the proprietory concern or the surviving partners are capable of carrying out and completing CONTRACT, he (the EMPLOYER)is entitled to cancel the CONTRACT for the uncompleted part without being in any way liable for any compensation payment to the estate of the diseased CONTRACTOR and/or to the surviving partners of the CONTRACTOR'S firm on account of the cancellation of CONTRACT. The decision of the EMPLOYER in such assessment shall be final and binding on the parties. In the event of such cancellation, the EMPLOYER shall not hold the estate of the diseased CONTRACTOR and/or the surviving partners of the CONTRACTOR'S firm liable for any damages for non-completion of CONTRACT. 32(B) TERMINATION OF CONTRACT IN CASE OF LIQUIDATION / BANKRUPTCY ETC. If the Contractor shall dissolve or become bankrupt or insolvent or cause or suffer any receiver to be appointed of his business of any assets thereof compound with his Creditors, or being a corporation commence to be wound up, not being a member‟s voluntary winding up for the purpose of amalgamation or reconstruction, or carry on its business under a Receiver for the benefits of its Creditors any of them, EMPLOYER shall be at liberty:- To terminate the contract forthwith upon coming to know of the happening of any such event as aforesaid by notice in writing to the Contractor or to give the Receiver or liquidator or other person, the option of carrying out the contract subject to his providing a guarantee upto an amount to be agreed upon by EMPLOYER for due and faithful performance of the contract. 32 (C) In case of termination of CONTRACT herein set forth (under clause 29.0) except under conditions of Force Majeure and termination after expiry of contract, the CONTRACTOR shall be put under holiday [i.e. neither any enquiry will be issued to the party by Bhagyanagar Gas Limited. against any type of tender nor their offer will be considered by BGL against any ongoing tender (s) where contract between BGL and that particular CONTRACTOR (as a bidder) has not been finalized] for three years from the date of termination by Bhagyanagar Gas Limited. to such CONTRACTOR. 33 Members of the employer not individually liable: 33.1 No Director, or official or employee of the EMPLOYER/ CONSULTANT shall in any way be personally bound or liable for the acts or obligations of the EMPLOYER under the CONTRACT or answerable for any default or omission in the observance or performance of any of the acts, matters or things which are herein contained. 34 Employer not bound by 34.1 The CONTRACTOR shall not be entitled to any increase on the personal representations: scheduled rates or any other right or claim whatsoever by reason of any representation, explanation statement or alleged representation, promise or guarantees given or alleged to have been given to him by any person. 35 Contractor's office at site: 35.1 The CONTRACTOR shall provide and maintain an office at the site for the accommodation of his agent and staff and such office shall be open at all reasonable (Sign & Seal of Bidder) Page 110 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II hours to receive instructions, notice or other communications. The CONTRACTOR at all time shall maintain a site instruction book and compliance of these shall be communicated to the ENGINEER-IN CHARGE from time to time and the whole document to be preserved and handed over after completion of works. 36 Contractor's subordinate staff and their conduct 36.1 The CONTRACTOR, on or after award of the WORK shall name and depute a qualified engineer having sufficient experience in carrying out work of similar nature, to whom the equipments, materials, if any, shall be issued and instructions for works given. The CONTRACTOR shall also provide to the satisfaction of the ENGINEER- IN- CHARGE sufficient and qualified staff to superintend the execution of the WORK, competent sub-agents, foremen and leading hands including those specially qualified by previous experience to supervise the types of works comprised in the CONTRACT in such manner as will ensure work of the best quality, expeditious working. Whenever in the opinion of the ENGINEER-IN- CHARGE additional properly qualified supervisory staff is considered necessary, they shall be employed by the CONTRACTOR without additional charge on accounts thereof. The CONTRACTOR shall ensure to the satisfaction of the ENGINEER-IN-CHARGE that SUB- CONTRACTORS, if any, shall provide competent and efficient supervision, over the work entrusted to them. 36.2 If and whenever any of the CONTRACTOR's or SUBCONTRACTOR'S agents, sub-agents, assistants, foremen, or other employees shall in the opinion of ENGINEER-IN- CHARGE be guilty of any misconduct or be incompetent or insufficiently qualified or negligent in the performance of their duties of that in the opinion of the EMPLOYER or the ENGINEER-IN-CHARGE, it is undesirable for administrative or any other reason for such person or persons to be employed in the works, the CONTRACTOR, is so directed by the ENGINEER-IN-CHARGE, shall at once remove such person or persons from employment thereon. Any person or persons so removed from the works shall not again be employed in connection with the WORKS without the written permission of the ENGINEER-IN- CHARGE. Any person so removed from the WORK shall be immediately re-placed at the expense of the CONTRACTOR by a qualified and competent substitute. Should the CONTRACTOR be requested to repatriate any person removed from the works he shall do so and shall bear all costs in connection herewith. 36.3 The CONTRACTOR shall be responsible for the proper behavior of all the staff, foremen, workmen, and others, and shall exercise a proper degree of control over them and in particular and without prejudice to the said generality, the CONTRACTOR shall be bound to prohibit and prevent any employees from trespassing or acting in any way detrimental or prejudicial to the interest of the community or of the properties or occupiers of land and properties in the neighborhood and in the event of such employee so trespassing, the CONTRACTOR shall be responsible therefore and relieve the EMPLOYER of all consequent claims or actions for damages or injury or any other grounds whatsoever. The decision of the ENGINEER-IN-CHARGE upon any matter arising under this clause shall be final. The CONTRACTOR shall be liable for any liability to EMPLOYER on account of deployment of CONTRACTOR's staff etc. or incidental or arising out of the execution of CONTRACT. (Sign & Seal of Bidder) Page 111 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II The CONTRACTOR shall be liable for all acts or omissions on the part of his staff, Foremen and Workmen and others in his employment, including misfeasance or negligence of whatever kind in the course of their work or during their employment, which are connected directly or indirectly with the CONTRACT. 36.4 If and when required by the EMPLOYER and CONTRACTOR's personnel entering upon the EMPLOYER's premises shall be properly identified by badges of a type acceptable to the EMPLOYER which must be worn at all times on EMPLOYER's premises. CONTRACTOR may be required to obtain daily entry passes for his staff/employees from EMPLOYER to work within operating areas. These being safety requirements, no relaxations on this account shall be given to CONTRACTOR. 37 Sub-letting of works: 37.1 No part of the CONTRACT nor any share or interest therein shall in any manner or degree be transferred, assigned or sublet by the CONTRACTOR directly or indirectly to any person, firm or corporation whatsoever without the consent in writing, of the ENGINEER/EMPLOYER except as provided for in the succeeding sub-clause. i) SUB-CONTRACTS FOR TEMPORARY WORKS ETC.: The EMPLOYER may give written consent to Sub- contract for the execution of any part of the WORK at the site, being entered in to by CONTRACTOR provided each individual Sub- contract is submitted to the ENGINEER-IN- CHARGE before being entered into and is approved by him. ii) LIST OF SUB-CONTRACTORS TO BE SUPPLIED: At the commencement of every month the CONTRACTOR shall furnish to the ENGINEER-IN- CHARGE list of all SUB-CONTRACTORS or other persons or firms engaged by the CONTRACTOR and working at the SITE during the previous month with particulars of the general nature of the Subcontract or works done by them. iii) CONTRACTOR'S LIABILITY NOT LIMITED BY SUBCONTRACTORS: Notwithstanding any sub-letting with such approval as aforesaid and notwithstanding that the ENGINEER-IN-CHARGE shall have received copies of any Subcontracts, the contractor shall be and shall remain solely responsible for the quality, proper and expeditious execution of the Contract in all respects as if such sub-letting or Subcontracting had not taken place, and as if such work had been done directly by the CONTRACTOR. The CONTRACTOR shall bear all responsibility for any act or omission on the part of subcontractors in regard to work to be performed under the CONTRACT. iv) EMPLOYER MAY TERMINATE SUB-CONTRACTS: If any SUB-CONTRACTOR engaged upon the works at the site executes any works which in the opinion of the ENGINEER-IN-CHARGE is not in accordance with the CONTRACT documents, the EMPLOYER may by written notice to the CONTRACTOR request him to terminate such subcontract and the CONTRACTOR upon the receipt of such notice shall terminate such Subcontract and dismiss the SUB-CONTRACTOR(S) and the later shall forthwith leave the works, failing which the EMPLOYER shall have the right to remove such SUB- CONTRACTOR(S) from the site. v) NO REMEDY FOR ACTION TAKEN UNDER THIS CLAUSE: (Sign & Seal of Bidder) Page 112 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II No action taken by the EMPLOYER under the clause shall relieve the CONTRACTOR of any of his liabilities under the CONTRACT or give rise to any right or compensation, extension of time or otherwise failing which the EMPLOYER shall have the right to remove such SUB-CONTRACTOR(S) from the site. 38 Power of entry: 38.1 If the CONTRACTOR shall not commence the WORK in the manner previously described in the CONTRACT documents or if he shall at any time in the opinion of the ENGINEER-IN-CHARGE. i) Fail to carry out the WORK in conformity with the CONTRACT documents, or ii) Fail to carry out the WORK in accordance with the Time Schedule, or iii) Substantially suspend work or the WORK for a period of fourteen days without authority from the ENGINEER-IN-CHARGE, or iv) Fail to carry out and execute the WORK to the satisfaction of the ENGINEER-IN- CHARGE, or v) Fail to supply sufficient or suitable construction plant, temporary works, labour, materials or things, or vi) Commit, suffer, or permit any other breach of any of the provisions of the CONTRACT on his part to be performed or observed or persist in any of the above mentioned breaches of the CONTRACT for fourteen days, after notice in writing shall have been given to the CONTRACTOR by the ENGINEER-IN-CHARGE requiring such breach to be remedied, or vii) If the CONTRACTOR shall abandon the WORK or viii) If the CONTRACTOR during the continuance of the CONTRACT shall become bankrupt, make any arrangement or composition with his creditors, or permit any execution to be levied or go into liquidation whether compulsory or voluntary not being merely a voluntary liquidation for the purpose of amalgamation or reconstruction then in any such case, the EMPLOYER shall have the power to enter upon the WORK and take possession thereof and of the materials, temporary WORK, construction plant, and stock thereon, and to revoke the CONTRACTOR's licence to use the same, and to complete the WORK by his agents, other CONTRACTORS or workmen or to relate the same upon any terms and to such other person, firm or corporation as the EMPLOYER in his absolute discretion may think proper to employ and for the purpose aforesaid to use or authorise the use of any materials, temporary work, CONSTRUCTION PLANT, and stock as aforesaid, without making payment or allowance to the CONTRACTOR for the said materials other than such as may be certified in writing by the ENGINEER- IN-CHARGE to be reasonable, and without making any payment or allowance to the CONTRACTOR for the use of the temporary said works, construction plant and stock or being liable for any loss or damage thereto, and if the EMPLOYER shall by reason of his taking possession of the WORK or of the WORK being completed by other CONTRACTOR (due account being taken of any such extra work or works which may or be omitted) then the amount of such excess as certified by the ENGINEER-IN- CHARGE shall be deducted from any money which may be due for work done by the CONTRACTOR under the CONTRACT and not paid for. Any deficiency shall forthwith be made good and paid to the EMPLOYER by the CONTRACTOR and the EMPLOYER shall have power to sell in such manner and for such price as he may think fit all or any of the construction plant, materials etc. constructed by or belonging (Sign & Seal of Bidder) Page 113 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II to and to recoup and retain the said deficiency or any part thereof out of proceeds of the sale. 39 Contractor's responsibility with the mechanical, electrical, intercommunication system, airconditioning contractors and other agencies: 39.1 Without repugnance of any other condition, it shall be the responsibility of the CONTRACTOR executing the work of civil construction, to work in close cooperation and coordinate the WORK with the Mechanical, Electrical, Air- conditioning and Intercommunication Contractor's and other agencies or their authorised representatives, in providing the necessary grooves, recesses, cuts and opening etc., in wall, slabs beams and columns etc. and making good the same to the desired finish as per specification, for the placement of electrical, intercommunication cables, conduits, air-conditioning inlets and outlets grills and other equipments etc. where required. For the above said requirements in the false ceiling and other partitions, the CONTRACTOR before starting-up the work shall in consultation with the Electrical, Mechanical, Intercommunication, Air-conditioning contractor and other agencies prepare and put-up a joint scheme, showing the necessary openings, grooves, recesses, cuts, the methods of fixing required for the WORK of the aforesaid, and the finishes therein, to the ENGINEER-IN-CHARGE and get the approval. The CONTRACTOR before finally submitting the scheme to the ENGINEER-IN- CHARGE, shall have the written agreement of the other agencies. The ENGINEER- IN-CHARGE, before communicating his approval to the scheme, with any required modification, shall get the final agreement of all the agencies, which shall be binding. No claim shall be entertained on account of the above. The CONTRACTOR shall confirm in all respects with provision of any statutory regulations, ordinances or byelaws of any local or duly constituted authorities or public bodies which may be applicable from time to time to the WORK or any temporary works. The CONTRACTOR shall keep the EMPLOYER indemnified against all penalties and liabilities of every kind, arising out of non- adherence to such stains, ordinances, laws, rules, regulations, etc. 40 Other agencies at site: 40.1 The CONTRACTOR shall have to execute the WORK in such place and conditions where other agencies will also be engaged for other works such as site grading, filling, and leveling, electrical and mechanical engineering works, etc. No claim shall be entertained due to WORK being executed in the above circumstances. 41 Notice: 41.1 TO THE CONTRACTOR: Any notice hereunder may be served on the CONTRACTOR or his duly authorised representative at the job site or may be served by registered mail direct to the address furnished by the CONTRACTOR. Proof of issue of any such notice could be conclusive of the CONTRACTOR having been duly informed of all contents therein. 41.2 TO THE EMPLOYER: Any notice to be given to the EMPLOYER under the terms of the CONTRACTOR shall be served by sending the same by Registered mail to or delivering the same at (Sign & Seal of Bidder) Page 114 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II the respective site offices of M/S. Bhagyanagar Gas Limited. addressed to the HEAD/SITE-IN-CHARGE. 42 Right of various interests: 42.1 i) The EMPLOYER reserves the right to distribute the work between more than One agency(ies). The CONTRACTOR shall cooperate and afford other agency (ies) reasonable opportunity for access to the WORK for the carriage and storage of materials and execution of their works. ii) Wherever the work being done by any department of the EMPLOYER or by other agency(ies) employed by the EMPLOYER is contingent upon WORK covered by this CONTRACT, the respective rights of the various interests involved shall be determined by the ENGINEER-IN-CHARGE to secure the completion of the various portions of the work in general harmony. 43 Patents and royalties: 43.1 The CONTRACTOR, if licensed under any patent covering equipment, machinery, materials or compositions of matter to be used or supplied or methods and process to be practiced or employed in the performance of this CONTRACT, agrees to pay all royalties and license fees which may be due with respect thereto. If any equipment, machinery, materials, composition of matters, be used or supplied or methods and processes to be practiced or employed in the performance of this CONTRACT,is covered by a patent under which the CONTRACTOR is not licensed then the CONTRACTOR before supplying or using the equipment, machinery materials, composition method or processes shall obtain such licenses and pay such royalties and license fees as may be necessary for performance of this CONTRACT. In the event the CONTRACTOR fails to pay any such royalty or obtain any such license, any suit for infringement of such patents which is brought against the CONTRACTOR or the EMPLOYER as a result such failure will be defended by the CONTRACTOR at his own expense and the CONTRACTOR will pay any damages and costs awarded in such suit. The CONTRACTOR shall promptly notify the EMPLOYER if the CONTRACTOR has acquired the knowledge of any plant under which a suit for infringement could be reasonably brought because of the use by the EMPLOYER of any equipment, machinery, materials, process, methods to be supplied hereunder. The CONTRACTOR agrees to and does hereby grant to EMPLOYER, together with the right to extend the same to any of the subsidiaries of the EMPLOYER as irrevocable, royalty free license to use in any country, any invention made by the CONTRACTOR or his employee in or as result of the performance of the WORK under the CONTRACT. 43.2 All charges on account of royalty. toilage, rent, octroi terminal or sales tax and/or other duties or any other levy on materials obtained for the work or temporary work or part thereof (excluding materials provided by the EMPLOYER) shall be borne by the CONTRACTOR. 43.3 The CONTRACTOR shall not sell or otherwise dispose of or remove except for the purpose of this CONTRACT, the sand, stone, clay, ballast, earth, rock or other substances, or materials obtained from any excavation made for the purpose of the WORK or any building or produce upon the site at the time of delivery of the (Sign & Seal of Bidder) Page 115 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II possession thereof, but all such substances, materials, buildings and produce shall be the property of the EMPLOYER provided that the CONTRACTOR may with the permission of the ENGINEER-IN-CHARGE, use the same for the purpose of the work by payment of cost of the same at such a rate as may be determined by the ENGINEER-IN- CHARGE. 43.4 The EMPLOYER shall indemnify and save harmless the CONTRACTOR from any loss on account of claims against CONTRACTOR for the contributory infringement of patent rights arising out and based upon the claim that the use of the EMPLOYER of the process included in the design prepared by the EMPLOYER and used in the operation of the plant infringes on any patent right. With respect to any subcontract entered into by CONTRACTOR pursuant to the provisions of the relevant clause hereof, the CONTRACTOR shall obtain from the SUB-CONTRACTOR an undertaking to provide the EMPLOYER with the same patent protection that CONTRACTOR is required to provide under the provisions of this clause. 44 Liens: 44.1 If, at any time there should be evidence or any lien or claim for which the EMPLOYER might have become liable and which is chargeable to the CONTRACTOR, the EMPLOYER shall have the right to retain out of any payment then due or thereafter to become due an amount sufficient to completely indemnify the EMPLOYER against such lien or claim and if such lien or claim be valid, the EMPLOYER may pay and discharge the same and deduct the amount so paid from any money which may be or may become due and payable to the CONTRACTOR. If any lien or claim remain unsettled after all payments are made, the CONTRACTOR shall refund or pay to the EMPLOYER all money that the latter may be compelled to pay in discharging such lien or claim including all costs and reasonable expenses. EMPLOYER reserves the right to do the same. 44.2 The EMPLOYER shall have lien on all materials, equipments including those brought by the CONTRACTOR for the purpose of erection, testing and commissioning of the WORK. 44.3 The final payment shall not become due until the CONTRACTOR delivers to the ENGINEER-IN-CHARGE a complete release or waiver of all liens arising or which may arise out of his agreement or receipt in full or certification by the CONTRACTOR in a form approved by ENGINEER-IN-CHARGE that all invoices for labour, materials, services have been paid in lien thereof and if required by the ENGINEER-IN-CHARGE in any case an affidavit that so far as the CONTRACTOR has knowledge or information the releases and receipts include all the labour and material for which a lien could be filled. 44.4 CONTRACTOR will indemnify and hold the EMPLOYER harmless, for a period of two years after the issue of FINAL CERTIFICATE, from all liens and other encumbrances against the EMPLOYER on account of debts or claims alleged to be due from the CONTRACTOR or his SUB-CONTRACTOR to any person including SUB- CONTRACTOR and on behalf of EMPLOYER will defend at his own expense, any claim or litigation brought against the EMPLOYER or the CONTRACTOR in connection therewith. CONTRACTOR shall defend or contest at his own expense any fresh claim or litigation by any person including his SUB-CONTRACTOR, till its satisfactory settlement even after the expiry of two years from the date of issue of FINAL CERTIFICATE. (Sign & Seal of Bidder) Page 116 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 45 Delays by employer or his authorised agents: 45.1 In case the CONTRACTOR's performance is delayed due to any act or omission on the part of the EMPLOYER or his authorised agents, then the CONTRACTOR shall be given due extension of time for the completion of the WORK, to the extent such omission on the part of the EMPLOYER has caused delay in the CONTRACTOR's performance of his WORK. 45.2 No adjustment in CONTRACT PRICE shall be allowed for reasons of such delays and extensions granted except as provided in TENDER DOCUMENT, where the EMPLOYER reserves the right to seek indulgence of CONTRACTOR to maintain the agreed Time Schedule of Completion. In such an event the CONTRACTOR shall be obliged for working by CONTRACTOR's personnel for additional time beyond stipulated working hours as also Sundays and Holidays and achieve the completion date/interim targets. 46 Payment if the contract is terminated: 46.1 If the CONTRACT shall be terminated as per Tender pursuant to Clause no. 29 of GCC, the CONTRACTOR shall be paid by the EMPLOYER in so far as such amounts or items shall not have already been covered by payments of amounts made to the CONTRACTOR for the WORK executed and accepted by ENGINEER-IN- CHARGE prior to the date of termination at the rates and prices provided for in the CONTRACT and in addition to the following: a) The amount payable in respect of any preliminary items, so far as the Work or service comprised therein has been carried out or performed and an appropriate portion as certified by ENGINEER-IN- CHARGE of any such items or service comprised in which has been partially carried out or performed. b) Any other expenses which the CONTRACTOR has expended for performing the WORK under the CONTRACT subject to being duly recommended by ENGINEER-IN-CHARGE and approved by EMPLOYER for payment, based on documentary evidence of his having incurred such expenses. 46.2 The CONTRACTOR will be further required to transfer the title and provide the following in the manner and as directed by the EMPLOYER. a) Any and all completed works. b) Such partially completed WORK including drawings, informations and CONTRACT rights as the CONTRACTOR has specially performed, produced or acquired for the performance of the CONTRACTOR. 47 No waiver of rights: 47.1 Neither the inspection by the EMPLOYER or any of their officials, employees, or agents nor any order by the EMPLOYER for payment of money or any payment for or acceptance of the whole or any part of the Work by the EMPLOYER nor any extension of time, nor any possession taken by EMPLOYER shall operate as a waiver of any provision of the CONTRACT, or of any power herein reserved to the EMPLOYER, or any right to damages herein provided, nor shall any waiver of any breach in the CONTRACT be held to be a waiver of any other subsequent breach. 48 Certificate not to affect right 48.1 No interim payment certificate(s) issued by the Engineer-in-Charge of employer and liability of contractor: the EMPLOYER, nor any sum paid on account by the (Sign & Seal of Bidder) Page 117 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II EMPLOYER, nor any extension of time for execution of the work granted by EMPLOYER shall affect or prejudice the rights of the Employer against the CONTRACTOR or relieve the CONTRACTOR of his obligations for the due performance of the CONTRACT, or be interpreted as approval of the WORK done or of the equipment supplied and no certificate shall create liability for the EMPLOYER to pay for alterations, amendments, variations or additional works not ordered, in writing, by EMPLOYER or discharge the liability of the CONTRACTOR for the payment of damages whether due, ascertained, or certified or not or any sum against the payment of which he is bound to indemnify the EMPLOYER. 49 Language and measures: 49.1 All documents pertaining to the CONTRACT including Specifications, Schedules, Notices, Correspondence, operating and maintenance Instructions, DRAWINGS, or any other writing shall be written in English language. The Metric System of measurement shall be used in the CONTRACT unless otherwise specified. 50 Transfer of title: 50.1 The title of Ownership of supplies furnished by the CONTRACTOR shall not pass on to the EMPLOYER for all Supplies till the same are finally accepted by the EMPLOYER after the successful completion of PERFORMANCE TEST and GUARANTEE TEST and issue of FINAL CERTIFICATE. 50.2 However, the EMPLOYER shall have the lien on all such works performed as soon as any advance or progressive payment is made by the EMPLOYER to the CONTRACTOR and the CONTRACTOR shall not subject these works for use other than those intended under this CONTRACT. 51 Release of information: 51.1 The CONTRACTOR shall not communicate or use in advertising, publicity, sales releases or in any other medium, photographs, or other reproduction of the Work under this CONTRACT or description of the site dimensions, quantity , quality or other information, concerning the Work unless prior written permission has been obtained from the EMPLOYER. 52 Brand names: 52.1 The specific reference in the SPECIFICATIONS and documents to any material by trade name, make or catalogue number shall be construed as establishing standard or quality and performance and not as limited competition. However, TENDERER may offer other similar equipments provided it meets the specified standard design and performance requirements. 53 Completion of contract: 53.1 Unless otherwise terminated under the provisions of any other relevant clause, this CONTRACT shall be deemed to have been completed at the expiration of the PERIOD OF LIABILITY as provided for under the CONTRACT. 54 Spares: 54.1 The CONTRACTOR shall furnish to the EMPLOYER all spares required for COMMISSIONING of the plants, recommendatory and/or mandatory spares, which (Sign & Seal of Bidder) Page 118 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II are required essential by the manufacturer/supplier. The same shall be delivered at SITE, 3(Three) months before COMMISSIONING. Also the CONTRACTOR should furnish the manufacturing drawings for fast wearing spares. 54.2 The CONTRACTOR guarantees the EMPLOYER that before the manufacturers of the equipments, plants and machineries go out of production of spare parts for the equipment furnished and erected by him, he shall give at least twelve (12) months' advance notice to the EMPLOYER, so that the latter may order his requirement of spares in one lot, if he so desires. SECTION-V Performance of Work 55 Execution of work: 55.1 All the Works shall be executed in strict conformity with the provisions of the CONTRACT Documents and with such explanatory detailed drawings, specification and instructions as may be furnished from time to time to the CONTRACTOR by the ENGINEER-IN-CHARGE whether mentioned in the CONTRACT or not. The CONTRACTOR shall be responsible for ensuring that works throughout are executed in the most substantial, proper and workmanlike manner with the quality of material and workmanship in strict accordance with the SPECIFICATIONS and to the entire satisfaction of the ENGINEER-IN-CHARGE. The CONTRACTOR shall provide all necessary materials equipment labour etc. for execution and maintenance of WORK till completion unless otherwise mentioned in the CONTRACT. 56 Co-ordination and inspection of work: 56.1 The coordination and inspection of the day-to-day work under the CONTRACT shall be the responsibility of the ENGINEER-IN-CHARGE. The written instruction regarding any particular job will normally be passed by the ENGINEER-IN- CHARGE or his authorised representative. A work order book will be maintained by the CONTRACTOR for each sector in which the aforesaid written instructions will be entered. These will be signed by the CONTRACTOR or his authorised representative by way of acknowledgement within 12 hours. 57 Work in monsoon and dewatering: 57.1 Unless otherwise specified elsewhere in the tender, the execution of the WORK may entail working in the monsoon also. The CONTRACTOR must maintain a minimum labour force as may be required for the job and plan and execute the construction and erection according to the prescribed schedule. No extra rate will be considered for such work in monsoon. 57.2 During monsoon and other period, it shall be the responsibility of the CONTRACTOR to keep the construction work site free from water at his own cost. 58 Work on sundays and holidays: 58.1 For carrying out Work on Sundays, and Holidays, the CONTRACTOR will approach the ENGINEER-IN-CHARGE or his representative at least two days in advance and obtain permission in writing. The CONTRACTOR shall observe all labour laws and other statutory rules and regulations in force. In case of any violations of such laws, rules and regulations, consequence if any, including the cost thereto shall be (Sign & Seal of Bidder) Page 119 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II exclusively borne by the CONTRACTOR and the EMPLOYER shall have no liability whatsoever on this account. 59 General conditions for construction and erection work: 59.1 The working time at the site of work is 48 hours per week. Overtime work is permitted in cases of need and the EMPLOYER will not compensate the same. Shift working at 2 or 3 shifts per day will become necessary and the CONTRACTOR should take this aspect into consideration for formulating his rates for quotation. No extra claims will be entertained by the EMPLOYER no this account. For carrying out work beyond working hours the CONTRACTOR will approach the ENGINEER-IN- CHARGE or his authorised representative and obtain his prior written permission. 59.2 The CONTRACTOR must arrange for the placement of workers in such a way that the delayed completion of the WORK or any part thereof for any reason whatsoever will not affect their proper employment. The EMPLOYER will not entertain any claim for idle time payment whatsoever. 59.3 The CONTRACTOR shall submit to the EMPLOYER/ENGINEER-INCHARGE reports at regular intervals regarding the state and progress of WORK. The details and proforma of the report will mutually be agreed after the award of CONTRACT. The CONTRACTOR shall provide display boards showing progress and labour strengths at worksite, as directed by the ENGINEER-IN-CHARGE. 60 Alterations in specifications, design and extra works: 60.1 The WORK covered under this CONTRACT having to be executed by the CONTRACTOR on a lumpsum firm price/item rate quoted by him, the EMPLOYER will not accept any proposals for changes in VALUE OF CONTRACT or extension in time on account of any such changes which may arise to the CONTRACTOR's scope of WORK as a result of detailed Engineering and thereafter during the execution of WORK. The only exception to this will be a case where the EMPLOYER requests in writing to the CONTRACTOR to upgrade the SPECIFICATIONS or the size of any major pieces of equipments, plant or machinery beyond what is normally required to meet the scope of WORK as defined in the CONTRACT DOCUMENT. In such cases, a change order will be initialed by the CONTRACTOR at the appropriate time for the EMPLOYER's prior approval giving the full back-up data for their review and for final settlement of any impact on price within 30 (thirty) days thereafter. 60.2 The ENGINEER-IN-CHARGE shall have to make any alterations in, omission from, additions to or substitutions for, the Schedule of Rates, the original specifications, drawings, designs and instructions that may appear to him to be necessary or advisable during the progress of the WORK and the CONTRACTOR shall be bound to carry out the such altered/ extra/ new items of WORK in accordance with any instructions which may be given to him in writing signed by the ENGINEER- INCHARGE, and such alterations, omissions, additions or substitutions shall not invalidate the CONTRACT and any altered, additional or substituted work which the CONTRACTOR may be directed to do in the manner above specified as part of the WORK shall be carried out by the CONTRACTOR on the same conditions in all respects on which he agreed to do the main WORK. The time of completion of WORK may be extended for the part of the particular job at the discretion of the (Sign & Seal of Bidder) Page 120 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II ENGINEER-IN- CHARGE, for only such alterations, additions or substitutions of the WORK, as he may consider as just and reasonable. The rates for such additional, altered or substituted WORK under this clause shall be worked out in accordance with the following provisions:- I. For Item Rate Contract a) If the rates for the additional, altered or substituted WORK are specified in the CONTRACT for the WORK, the CONTRACTOR is bound to carry on the additional, altered or substituted WORK at the same rates as are specified in the CONTRACT. b) If the rates for the additional, altered or substituted WORK are not specifically provided in the CONTRACT for the WORK, the rates will be derived from the rates for similar class of WORK as are specified in the CONTRACT for the WORK. The opinion of the ENGINEER-IN- CHARGE, as to whether or not the rates can be reasonably so derived from the items in this CONTRACT will be final and binding on the CONTRACTOR. c) If the rates for the altered, additional or substituted WORK cannot be determined in the manner specified in sub-clause(s) and (b) above, then the CONTRACTOR shall, within 7 days of the date of receipt of order to carry out the WORK, inform the ENGINEER-IN-CHARGE of the rates which it is his intention to charge for such class of WORK, supported by analysis of the rate or rates claimed, and the ENGINEER- IN-CHARGE shall determine the rate or rates on the basis of the prevailing market rates, labour cost at schedule of labour rates plus 10% to cover contractor's supervision, overheads and profit and pay the CONTRACTOR accordingly. The opinion of the ENGINEER- IN- CHARGE as to current market rates of materials and the quantum of labour involved per unit of measurement will be final and binding on the CONTRACTOR. d) Where the item of work will be executed through nominated specialist agency as approved by the ENGINEER-IN-CHARGE, then the actual amount paid to such nominated agency supported by documentary evidence and as certified by ENGINEER-IN-CHARGE shall be considered plus 10% (ten percent) to cover all contingencies, overhead, profits to arrive at the rates. e) Provisions contained in the Sub-clause (a) & (d) above shall, however, not apply for the following:- Where the value of additions of new items together with the value of alterations, additions/deletions or substitutions does not exceed by or is not less than plus/minus (+_)25% of the VALUE OF CONTRACT. The item rates in the Schedule of Rates shall hold good for all such variations between the above mentioned limits, irrespective of any increase/decrease of quantities in the individual items of Schedule of Rates. Where the value of addition of new items together with the value of alterations, additions/deletions or substitutions reduces more than 25% of the contract value but is within the following limits the tenderer shall be paid compensation for decrease in the value of work, as follows: (Sign & Seal of Bidder) Page 121 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 S.No. Range of Variation A Beyond (+) 25% upto &inclusive of (+) 50% B Beyond (-) 25% upto &inclusive of (-) 50% II. For Lumpsum Contracts VOLUME I OF II Percentage compensationfor decrease in the value of work in the respective range No increase and/or decrease shall be applicable for the Schedule of Rates (The rates quoted for this increase shall be valid). For reduction beyond 25% contractor shall be compensated by an amount equivalent to 10% of the reduction in value of the contract as awarded. For example if the actual contract value is 70% of awarded value then compensation shall be 10% of (75-70) i.e. 0.5% of awarded contract value. CONTRACTOR shall, within 7 days of the date of receipt of order to carry out the WORK, inform the ENGINEER-INCHARGE of the rates which it is his intention to charge for such class of WORK, supported by analysis of the rate or rates claimed, and the ENGINEER-IN-CHARGE shall determine the rate or rates on the basis of the prevailing market rates, labour cost at schedule of labour rates plus 10% to cover contractor's supervision, overheads and profit and pay the CONTRACTOR accordingly. The opinion of the ENGINEER- IN-CHARGE as to current market rates of materials and the quantum of labour involved per unit of measurement will be final and binding on the CONTRACTOR. 61 Drawings to be supplied by the employer 61.1 The drawings attached with tender are o0nly for the general guidance to the CONTRACTOR to enable him to visualize the type of work contemplated and scope of work involved. The CONTRACTOR will be deemed to have studied the DRAWINGS and formed an idea about the WORK involved. 61.2 Detailed working drawings on the basis of which actual execution of the WORK is to proceed, will be furnished from time to time during the progress of the work. The CONTRACTOR shall be deemed to have gone through the DRAWINGS supplied to him thoroughly and carefully and in conjunction with all other connected drawings and bring to the notice of the ENGINEER-IN-CHARGE discrepancies, if any, therein before actually carrying out the Work. 61.3 Copies of all detailed working drawings relating to the WORK shall be kept at the CONTRACTOR's office on the site and shall be made available to the ENGINEER- IN- CHARGE at any time during the CONTRACT. The drawings and other documents issued by the EMPLOYER shall be returned to the EMPLOYER on completion of the WORK. 62 Drawings to be supplied by the contractor: 62.1 The drawings/date which are to be furnished by the CONTRACTOR are enumerated in the special conditions of contract, and shall be furnished within the specified time. (Sign & Seal of Bidder) Page 122 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 62.2 Where approval/review of drawings before manufacture/ construction/fabrication has been specified, it shall be CONTRACTOR's responsibility to have these drawings prepared as per the directions of ENGINEER-IN-CHARGE and got approved before proceeding with manufacture/construction/fabrication as the case may be. Any change that may have become necessary in these drawings during the execution of the work shall have to be carried out by the CONTRACTOR to the satisfaction of ENGINEER- IN-CHARGE at no extra cost. All final drawings shall bear the certification stamp as indicated below duly signed by both the CONTRACTOR and ENGINEER-IN- CHARGE. "Certified true for ___________________________________ (Name of Work) Agreement No.___________________________________________________ Signed:_________________ _________________ (CONTRACTOR) (ENGINEER-IN-CHARGE) 62.3 The DRAWINGS submitted by the CONTRACTOR shall be reviewed by the ENGINEER-IN-CHARGE as far as practicable within 3 (Three) weeks and shall be modified by the CONTRACTOR, if any modifications and/or corrections are required by the ENGINEER-IN-CHARGE. The CONTRACTOR shall incorporate such modifications and/or corrections and submit the final drawings for approval. Any delays arising out of failure by the CONTRACTOR to rectify the drawing in good time shall not alter the Contract Completion Time. 62.4 As built drawings showing all corrections, adjustments etc. shall be furnished by the CONTRACTOR in six copies and one transparent for record purposed to the EMPLOYER. 63 Setting out works: 63.1 The ENGINEER-IN-CHARGE shall furnish the CONTRACTOR with only the four corners of the Works site and a level bench mark and the CONTRACTOR shall set out the Works and shall provide an efficient staff for the purpose and shall be solely responsible for the accuracy of such setting out. 63.2 The CONTRACTOR shall provide, fix and be responsible for the maintenance of all stakes, templates, level marks, profiles and other similar things and shall take all necessary precautions to prevent their removal or disturbance and shall be responsible for the consequence of such removal or disturbance should the same take place and for their efficient and timely reinstatement. The CONTRACTOR shall also be responsible for the maintenance of all existing survey marks, boundary marks, distance marks and center line marks, either existing or supplied and fixed by the CONTRACTOR. The work shall be set out to the satisfaction of the ENGINEER-IN- CHARGE. The approval there of joining with the CONTRACTOR by the ENGINEER- IN-CHARGE in setting out the work, shall not relieve the CONTRACTOR of any of his responsibility. 63.3 Before beginning the Works, the CONTRACTOR shall at his own cost, provide all necessary reference and level posts, pegs, bamboos, flags, ranging rods, strings and other materials for proper layout of the works in accordance with the schemes for bearing marks acceptable to the ENGINEER-IN-CHARGE. The center, longitudinal or face lines and cross lines shall be marked by means of small masonry pillars. Each pillar shall have distinct mark at the centre to enable theodolite to be set over it. No work shall be started until all these points are checked and approved by the ENGINEER-IN-CHARGE in writing but such approval shall not relieve the (Sign & Seal of Bidder) Page 123 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II CONTRACTOR of any of his responsibilities. The CONTRACTOR shall also provide all labour, material and other facilities, as necessary, for the proper checking of layout and inspection of the points during construction. 63.4 Pillars bearing geodetic marks located at the sites of units of WORKS under construction should be protected and fenced by the CONTRACTOR. 63.5 On completion of WORK, the CONTRACTOR must submit the geodetic documents according to which the WORK was carried out. 64 Responsibility for level and alignment: 64.1 The CONTRACTOR shall be entirely and exclusively responsible for the horizontal and vertical alignment, the levels and correctness of every part of the WORK and shall rectify effectively any errors or imperfections therein, such rectifications shall be carried out by the CONTRACTOR, at his own cost, when instructions are issued to that effect by the ENGINEER- IN-CHARGE. 65 Materials to be supplied by contractor: 65.1 The CONTRACTOR shall procure and provide within the VALUE OF CONTRACT the whole of the materials required for the construction including steels, cement and other building materials, tools, tackles, construction plant and equipment for the completion and maintenance of the WORK except the materials which will be issued by the EMPLOYER and shall make his own arrangement for procuring such materials and for the transport thereof. The EMPLOYER may give necessary recommendation to the respective authority if so desired by the CONTRACTOR but assumes no further responsibility of any nature. The EMPLOYER will insist on the procurement of materials which bear ISI stamp and/or which are supplied by reputed suppliers. 65.2 The CONTRACTOR shall properly store all materials either issued to him or brought by him to the SITE to prevent damages due to rain, wind, direct exposure to sun, etc. as also from theft, pilferage, etc. for proper and speedy execution of his works. The CONTRACTOR shall maintain sufficient stocks of all materials required by him. 65.3 No material shall be dispatched from the CONTRACTOR's stores before obtaining the approval in writing of the ENGINEER-IN-CHARGE. 66 Stores supplied by the employer: 66.1 If the SPECIFICATION of the WORK provides for the use of any material of special description to be supplied from the EMPLOYER's stores or it is required that the CONTRACTOR shall use certain stores to be provided by the ENGINEER-IN- CHARGE, such materials and stores, and price to be charged there for as hereinafter mentioned being so far as practicable for the convenience of the CONTRACTOR, but not so as in any way to control the meaning or effect of the CONTRACT, the CONTRACTOR shall be bound to purchase and shall be supplied such materials and stores as are from time to time required to be used by him for the purpose of the CONTRACT only. The sums due from the CONTRACTOR for the value of materials supplied by the EMPLOYER will be recovered from the running account bill on the basis of the actual consumption of materials in the works covered and for which the running account bill has been prepared. After the completion of the WORK, however, the CONTRACTOR has to account for the full quantity of materials supplied to him as per relevant clauses in this document. (Sign & Seal of Bidder) Page 124 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 66.2 The value of the stores/materials as may be supplied to the CONTRACTOR by the EMPLOYER will be debited to the CONTRACTOR's account at the rates shown in the schedule of materials and if they are not entered in the schedule, they will be debited at cost price, which for the purpose of the CONTRACT shall include the cost of carriage and all other expenses whatsoever such as normal storage supervision charges which shall have been incurred in obtaining the same at the EMPLOYER's stores. All materials so supplied to the CONTRACTOR shall remain the absolute property of the EMPLOYER and shall not be removed on any account from the SITE of the WORK, and shall be at all times open for inspection to the ENGINEER-IN- CHARGE. Any such materials remaining unused at the time of the completion or termination of the CONTRACT shall be returned to the EMPLOYER's stores or at a place as directed by the ENGINEER-IN-CHARGE in perfectly good condition at CONTRACTOR's cost. 67 Conditions for issue of materials: 67.1 i) Materials specified as to be issued by the EMPLOYER will be supplied to the CONTRACTOR by the EMPLOYER form his stores. It shall be responsibility of the CONTRACTOR to take delivery of the materials and arrange for its loading, transport and unloading at the SITE of WORK at his own cost. The materials shall be issued between the working hours and as per the rules of the EMPLOYER as framed from time to time. ii) The CONTRACTOR shall bear all incidental charges for the storage and safe custody of materials at site after these have been issued to him. iii) Materials specified as to be issued by the EMPLOYER shall be issued in standard sizes as obtained from the manufacturers. iv) The CONTRACTOR shall construct suitable Godowns at the SITE of WORK for storing the materials safe against damage by rain, dampness, fire, theft etc. He shall also employ necessary watch and ward establishment for the purpose. v) It shall be duty of the CONTRACTOR to inspect the materials supplied to him at the time of taking delivery and satisfy himself that they are in good condition. After the materials have been delivered by the EMPLOYER, it shall be the responsibility of the CONTRACTOR to keep them in good condition and if the materials are damaged or lost, at any time, they shall be repaired and/or replaced by him at his own cost according to the instructions of the ENGINEER-IN-CHARGE. vi) The EMPLOYER shall not be liable for delay in supply or non-supply of any materials which the EMPLOYER has undertaken to supply where such failure or delay is due to natural calamities, act of enemies, transport and procurement difficulties and any circumstances beyond the control of the EMPLOYER. In no case, the CONTRACTOR shall be entitled to claim any compensation or loss suffered by him on this account. vii) It shall be responsibility of the CONTRACTOR to arrange in time all materials required for the WORK other than those to be supplied by the EMPLOYER. If, however, in the opinion of the ENGINEER-IN-CHARGE the execution of the WORK is likely to be delayed due to the CONTRACTOR's inability to make arrangements for supply of materials which normally he has to arrange for, the ENGINEER-IN-CHARGE shall (Sign & Seal of Bidder) Page 125 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II have the right at his own discretion to issue such materials, if available with the EMPLOYER or procure the materials from the market or as elsewhere and the CONTRACTOR will be bound to take such materials at the rates decided by the ENGINEER-IN-CHARGE. This, however, does not in any way absolve the CONTRACTOR from responsibility of making arrangements for the supply of such materials in part or in full, should such a situation occur nor shall this constitute a reason for the delay in the execution of the WORK. viii) None of the materials supplied to the CONTRACTOR will be utilised by the CONTRACTOR for manufacturing item which can be obtained as supplied from standard manufacturer in finished form. ix) The CONTRACTOR shall, if desired by the ENGINEERIN- CHARGE, be required to execute an Indemnity Bond in the prescribed form for safe custody and accounting of all materials issued by the EMPLOYER. x) The CONTRACTOR shall furnish to the ENGINEER-INCHARGE sufficiently in advance a statement showing his requirement of the quantities of the materials to be supplied by the EMPLOYER and the time when the same will be required by him for the works, so as to enable the ENGINEER- IN-CHARGE to make necessary arrangements for procurement and supply of the material. xi) Account of the materials issued by the EMPLOYER shall be maintained by CONTRACTOR indicating the daily receipt, consumption and balance in hand. This account shall be maintained in a manner prescribed by the ENGINEER-IN-CHARGE along with all connected papers viz. requisitions, issues, etc., and shall be always available for inspection in the CONTRACTOR's office at SITE. xii) The CONTRACTOR should see that only the required quantities of materials are got issued. The CONTRACTOR shall not be entitled to cartage and incidental charges for returning the surplus materials, if any, to the stores wherefrom they were issued or to the place as directed by the ENGINEER-IN- CHARGE. xiii) Materials/Equipment(s) supplied by EMPLOYER shall not be utilised for any purpose(s) than issued for. 68 Material procured with assistance of employer/return of surplus: 68.1 Notwithstanding anything contained to the contrary in any or all the clauses of this CONTRACT where any materials for the execution of the CONTRACT are procured with the assistance of the EMPLOYER either by issue from EMPLOYER's stock or purchases made under order or permits or licences issued by Government, the CONTRACTOR shall hold the said materials as trustee for the EMPLOYER and use such materials economically and solely for the purpose of the CONTRACT and not dispose them off without the permission of the EMPLOYER and return, if required by the ENGINEER-IN-CHARGE, shall determine having due regard to the condition of the materials. The price allowed to the CONTRACTOR, however, shall not exceed the amount charged to him excluding the storage charges, if any. The decision of the ENGINEER-IN-CHARGE shall be final and conclusive in such matters. In the event of breach of the aforesaid condition, the CONTRACTOR shall, in terms of the licences or permits and/or criminal breach of trust, be liable to compensate the (Sign & Seal of Bidder) Page 126 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II EMPLOYER at double rate or any higher rate, in the event of those materials at that time having higher rate or not being available in the market, then any other rate to be determined by the ENGINEER-IN-CHARGE and his decision shall be final and conclusive. 69 Materials obtained from dismantling: 69.1 If the CONTRACTOR in the course of execution of the WORK is called upon to dismantle any part for reasons other than those stipulated in Clauses 74 and 77 hereunder, the materials obtained in the WORK of dismantling etc., will be considered as the EMPLOYER's property and will be disposed off to the best advantage of the EMPLOYER. 70 Articles of value found: 70.1 All gold, silver and other minerals of any description and all precious stones, coins, treasure relics, antiquities and other similar things which shall be found in, under or upon the SITE, shall be the property of the EMPLOYER and the CONTRACTOR shall duly preserve the same to the satisfaction of the ENGINEER-IN-CHARGE and shall from time to time deliver the same to such person or persons indicated by the EMPLOYER. 71 Discrepancies between instructions: 71.1 Should any discrepancy occur between the various instructions furnished to the CONTRACTOR, his agent or staff or any doubt arises as to the meaning of any such instructions or should there be any misunderstanding between the CONTRACTOR's staff and the ENGINEER-IN- CHARGE's staff, the CONTRACTOR shall refer the matter immediately in writing to the ENGINEER-IN-CHARGE whose decision thereon shall be final and conclusive and no claim for losses alleged to have been caused by such discrepancies between instructions, doubts, or misunderstanding shall in any event be admissible. 72 Action where no specification is issued: 72.1 In case of any class of WORK for which there is no SPECIFICATION supplied by the EMPLOYER as mentioned in the Tender Documents such WORK shall be carried out in accordance with Indian Standard Specifications and if the Indian Standard Specifications do not cover the same, the WORK should be carried out as per standard Engineering Practice subject to the approval of the ENGINEER-IN- CHARGE. 73 Inspection of works: 73.1 The ENGINEER-IN-CHARGE will have full power and authority to inspect the WORK at any time wherever in progress either on the SITE or at the CONTRACTOR's premises/workshops wherever situated, premises/ workshops of any person, firm or corporation where WORK in connection with the CONTRACT may be in hand or where materials are being or are to be supplied, and the CONTRACTOR shall afford or procure for the ENGINEER-IN- CHARGE every (Sign & Seal of Bidder) Page 127 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II facility and assistance to carry out such inspection. The CONTRACTOR shall, at all time during the usual working hours and at all other time at which reasonable notice of the intention of the ENGINEER-IN- CHARGE or his representative to visit the WORK shall have been given to the CONTRACTOR, either himself be present or receive orders and instructions, or have a responsible agent duly accredited in writing, present for the purpose. Orders given to the CONTRACTOR's agent shall be considered to have the same force as if they had been given to the CONTRACTOR himself. The CONTRACTOR shall give not less than seven days notice in writing to the ENGINEER-IN-CHARGE before covering up or otherwise placing beyond reach of inspection and measurement of any work in order that the same may be inspected and measured. In the event of breach of above the same shall be uncovered at CONTRACTOR's expense for carrying out such measurement or inspection. 73.2 No material shall be dispatched from the CONTRACTOR's stores before obtaining the approval in writing of the Engineer-in-Charge. The CONTRACTOR is to provide at all time during the progress of the WORK and the maintenance period, proper means of access with ladders, gangways etc. and the necessary attendance to move and adopt as directed for inspection or measurements of the WORK by the ENGINEERIN- CHARGE. 73.3 The CONTRACTOR shall make available to the ENGINEER-IN-CHARGE free of cost all necessary instruments and assistance in checking or setting out of WORK and in the checking of any WORK made by the CONTRACTOR for the purpose of setting out and taking measurements of WORK. 74 Tests for quality of work: 74.1 All workmanship shall be of the respective kinds described in the CONTRACT DOCUMENTS and in accordance with the instructions of the ENGINEER-IN- CHARGE and shall be subjected from time to time to such test at CONTRACTOR's cost as the ENGINEER-IN-CHARGE may direct at the place of manufacture or fabrication or on the site or at all or any such places. The CONTRACTOR shall provide assistance, instruments, labour and materials as are normally required for examining, measuring and testing any workmanship as may be selected and required by the ENGINEER-IN-CHARGE. 74.2 All the tests that will be necessary in connection with the execution of the WORK as decided by the ENGINEER- IN-CHARGE shall be carried out at the field testing laboratory of the EMPLOYER by paying the charges as decided by the EMPLOYER from time to time. In case of non- availability of testing facility with the EMPLOYER, the required test shall be carried out at the cost of CONTRACTOR at Government or any other testing laboratory as directed by ENGINEER-IN-CHARGE. 74.3 If any tests are required to be carried out in conjunction with the WORK or materials or workmanship not supplied by the CONTRACTOR, such tests shall be carried out by the CONTRACTOR as per instructions of ENGINEER-IN-CHARGE and cost of such tests shall be reimbursed by the EMPLOYER. 75 Samples for approval: 75.1 The CONTRACTOR shall furnish to the ENGINEER-IN-CHARGE for approval, when requested or if required by the specifications, adequate samples of all materials and finished to be used in the WORK. Such samples shall be submitted before the WORK is commenced and in ample time to permit tests and examinations thereof. All (Sign & Seal of Bidder) Page 128 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II materials furnished and finishes applied in actual WORK shall be fully equal to the approved samples. 76 Action and compensation in case of bad work: 76.1 If it shall appear to the ENGINEER-IN-CHARGE that any work has been executed with unsound, imperfect or unskilled workmanship, or with materials of any inferior description, or that any materials or articles provided by the CONTRACTOR for the execution of the WORK are unsound, or of a quality inferior to that contracted for, or otherwise not in accordance with the CONTRACT, the CONTRACTOR shall on demand in writing from the ENGINEER-IN-CHARGE or his authorised representative specifying the WORK, materials or articles complained of notwithstanding that the same may have been inadvertently passed, certified and paid for, forthwith rectify or remove and reconstruct the WORK so specified and provide other proper and suitable materials or articles at his own cost and in the event of failure to do so within the period specified by the ENGINEER-IN-CHARGE in his demand aforesaid, the CONTRACTOR shall be liable to pay compensation at the rate of 1 % (One percent) of the estimated cost of the whole WORK, for every week limited to a maximum of 10% (ten percent)of the value of the whole WORK, while his failure to do so shall continue and in the case of any such failure the ENGINEER- IN-CHARGE may on expiry of notice period rectify or remove and re-execute the WORK or remove and replaced with others, the materials or articles complained of to as the case may be at the risk and expense in all respects of the CONTRACTOR. The decision of the Engineering-in-charge as to any question arising under this clause shall be final and conclusive. 77 Suspension of works: 77.1 Subject to the provisions of sub-para (ii) of this clause, the CONTRACTOR shall, if ordered in writing by the ENGINEER-IN-CHARGE, or his representative, temporarily suspend the WORKS or any part thereof for such written order, proceed with the WORK therein ordered to be suspended until, he shall have received a written order to proceed therewith. The CONTRACTOR shall not be entitled to claim compensation for any loss or damage sustained by him by reason of temporary suspension of the WORKS aforesaid. An extension of time for completion, corresponding with the delay caused by any such suspension of the WORKS as aforesaid will be granted to the CONTRACTOR should he apply for the same provided that the suspension was not consequent to any default or failure on the part of the CONTRACTOR. ii) In case of suspensions of entire WORK, ordered in writing by ENGINEER-IN-CHARGE, for a period of more than two months, the CONTRACTOR shall have the option to terminate the CONTRACT. 78 Employer may do part of work: 78.1 Upon failure of the CONTRACTOR to comply with any instructions given in accordance with the provisions of this CONTRACT the EMPLOYER has the alternative right, instead of assuming charge of entire WORK, to place additional labour force, tools, equipments and materials on such parts of the WORK, as the EMPLOYER may designate or also engage another CONTRACTOR to carry out the WORK. In such cases, the EMPLOYER shall deduct from the amount which otherwise might become due to the CONTRACTOR, the cost of such work and (Sign & Seal of Bidder) Page 129 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II material with ten percent (10%) added to cover all departmental charges and should the total amount thereof exceed the amount due to the CONTRACTOR, the CONTRACTOR shall pay the difference to the EMPLOYER. 79 Possession prior to completion: 79.1 The ENGINEER-IN-CHARGE shall have the right to take possession of or use any completed or partially completed WORK or part of the WORK. Such possession or use shall not be deemed to be an acceptance of any work completed in accordance with the CONTRACT agreement. If such prior possession or use by the ENGINEER- IN- CHARGE delays the progress of WORK, equitable adjustment in the time of completion will be made and the CONTRACT agreement shall be deemed to be modified accordingly. 80 (Defects liability period) twelve months period of liability from the date of issue of completion certificate: 80.1 The CONTRACTOR shall guarantee the installation/WORK for a period of 12 months from the date of completion of WORK as certified by the ENGINEER-IN- CHARGE which is indicated in the Completion Certificate. Any damage or defect that may arise or lie undiscovered at the time of issue of Completion Certificate, connected in any way with the equipment or materials supplied by him or in the workmanship, shall be rectified or replaced by the CONTRACTOR at his own expense as deemed necessary by the ENGINEER-IN-CHARGE or in default, the ENGINEER- IN-CHARGE may carry out such works by other work and deduct actual cost incurred towards labour, supervision and materials consumables or otherwise plus 100% towards overheads (of which the certificate of ENGINEER-IN- CHARGE shall be final) from any sums that may then be or at any time thereafter, become due to the CONTRACTOR or from his Contract Performance Security, or the proceeds of sale thereof or a sufficient part on thereof. 80.2 If the CONTRACTOR feels that any variation in WORK or in quality of materials or proportions would be beneficial or necessary to fulfill the guarantees called for, he shall bring this to the notice of the ENGINEERIN- CHARGE in writing. If during the period of liability any portion of the WORK/equipment, is found defective and is rectified/ replaced, the period of liability for such equipment/ portion of WORK shall be operative from the date such rectification/ replacement are carried out and Contract Performance Guarantee shall be furnished separately for the extended period of liability for that portion of WORK/ equipment only. Notwithstanding the above provisions the supplier's, guarantees/warantees for the replaced equipment shall also be passed on to the EMPLOYER. 80.3 LIMITATION OF LIABILITY Notwithstanding anything contrary contained herein, the aggregate total liability of CONTRACTOR under the Agreement or otherwise shall be limited to 100% of Agreement / Contract Value. However, neither party shall be liable to the other party for any indirect and consequential damages, loss of profits or loss of production. 81 Care of works: 81.0 From the commencement to completion of the WORK, the CONTRACTOR shall take full responsibility for the care for all works including all temporary works and in (Sign & Seal of Bidder) Page 130 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II case any damages, loss or injury shall happen to the WORK or to any part thereof or to any temporary works from any cause whatsoever, shall at his own cost repair and make good the same so that at completion the WORK shall be in good order and in conformity in every respects with the requirement of the CONTRACT and the ENGINEER-IN- CHARGE's instructions. 81.1 DEFECTS PRIOR TO TAKING OVER: If at any time, before the WORK is taken over, the ENGINEER-IN-CHARGE shall: a) Decide that any works done or materials used by the CONTRACTOR or by any SUB-CONTRACTOR is defective or not in accordance with the CONTRACT, or that the works or any portion thereof are defective, or do not fulfill the requirements of CONTRACT (all such matters being hereinafter, called `Defects' in this clause), and b) As soon as reasonably practicable, gives to the CONTRACTOR notice in writing of the said decision, specifying particulars of the defects alleged to exist or to have occurred, then the CONTRACTOR shall at his own expenses and with all speed make good the defects so specified. In case CONTRACTOR shall fail to do so, the EMPLOYER may take, at the cost of the CONTRACTOR, such steps as may in all circumstances, be reasonable to make good such defects. The expenditure so incurred by the EMPLOYER will be recovered from the amount due to the CONTRACTOR. The decision of the ENGINEER-IN-CHARGE with regard to the amount to be recovered from the CONTRACTOR will be final and binding on the CONTRACTOR. As soon as the WORK has been completed in accordance with the CONTRACT (except in minor respects that do not affect their use for the purpose for which they are intended and except for maintenance there of provided in clause 80.1 of General Conditions of Contract) and have passed the tests on completion, the ENGINEER-IN-CHARGE shall issue a certificate (hereinafter called Completion Certificate) in which he shall certify the date on which the WORK have been so completed and have passed the said tests and the EMPLOYER shall be deemed to have taken over the WORK on the date so certified. If the WORK has been divided into various groups in the CONTRACT, the EMPLOYER shall be entitled to take over any group or groups before the other or others and there upon the ENGINEER-IN-CHARGE shall issue a Completion Certificate which will, however, be for such group or groups so taken over only. In such an event if the group /section/ part so taken over is related, to the integrated system of the work, not withstanding date of grant of Completion Certificate for group/ section/ part. The period of liability in respect of such group/ section/ part shall extend 12 (twelve) months from the date of completion of WORK. 81.2 DEFECTS AFTER TAKING OVER: In order that the CONTRACTOR could obtain a COMPLETION CERTIFICATE he shall make good, with all possible speed, any defect arising from the defective materials supplied by the CONTRACTOR or workmanship or any act or omission of the CONTRACT or that may have been noticed or developed, after the works or groups of the works has been taken over, the period allowed for carrying out such WORK will be normally one month. If any defect be not remedied within a (Sign & Seal of Bidder) Page 131 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II reasonable time, the EMPLOYER may proceed to do the WORK at CONTRACTOR's risk and expense and deduct from the final bill such amount as may be decided by the EMPLOYER. If by reason of any default on the part of the CONTRACTOR a COMPLETION CERTIFICATE has not been issued in respect of any portion of the WORK within one month after the date fixed by the CONTRACT for the completion of the WORK, the EMPLOYER shall be at liberty to use the WORK or any portion thereof in respect of which a completion certificate has not been issued, provided that the WORK or the portion thereof so used as aforesaid shall be afforded reasonable opportunity for completing these works for the issue of Completion Certificate. 82 Guarantee/transfer of guarantee: 82.1 For works like water-proofing, acid and alkali resisting materials, pre-construction soil treatment against termite or any other specialized works etc. the CONTRACTOR shall invariably engage SUB-CONTRACTORS who are specialists in the field and firms of repute and such a SUB-CONTRACTOR shall furnish guarantees for their workmanship to the EMPLOYER, through the CONTRACTOR. In case such a SUB- CONTRACTOR/ firm is not prepared to furnish a guarantee to the EMPLOYER, the CONTRACTOR shall give that guarantee to the EMPLOYER directly. 83 Training of employer's personnel: 83.1 The CONTRACTOR undertakes to provide training to Engineering personnel selected and sent by the EMPLOYER at the works of the CONTRACTOR without any cost to the EMPLOYER. The period and the nature of training for the individual personnel shall be agreed upon mutually between the CONTRACTOR and the EMPLOYER. These engineering personnel shall be given special training at the shops, where the equipment will be manufactured and/ or in their collaborator's works and where possible, in any other plant where equipment manufactured by the CONTRACTOR or his collaborators is under installation or test to enable those personnel to become familiar with the equipment being furnished by the CONTRACTOR. EMPLOYER shall bear only the to and fro fare of the said engineering personnel. 84 Replacement of defective parts and materials: 84.1 If during the progress of the WORK, EMPLOYER shall decide and inform in writing to the CONTRACTOR, that the CONTRACTOR has manufactured any plant or part of the plant unsound or imperfect or has furnished plant inferior to the quality specified, the CONTRACTOR on receiving details of such defects or deficiencies shall at his own expenses within 7 (seven) days of his receiving the notice, or otherwise within such time as may be reasonably necessary for making it good, proceed to alter, re-construct or remove such work and furnish fresh equipments upto the standards of the specifications. In case the CONTRACTOR fails to do so, EMPLOYER may on giving the CONTRACTOR 7 (seven) day's notice in writing of his intentions to do so, proceed to remove the portion of the WORK so complained of and at the cost of CONTRACTOR's, perform all such works or furnish all such equipments provided that nothing in the clause shall be deemed to deprive the EMPLOYER of or affect any rights under the CONTRACT, the EMPLOYER may otherwise have in respect of such defects and deficiencies. (Sign & Seal of Bidder) Page 132 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 84.2 The CONTRACTOR's full and extreme liability under this clause shall be satisfied by the payments to the EMPLOYER of the extra cost, of such replacements procured including erection/installation as provided for in the CONTRACT; such extra cost being the ascertained difference between the price paid by the EMPLOYER for such replacements and the CONTRACT price portion for such defective plants and repayments of any sum paid by the EMPLOYER to the CONTRACTOR in respect of such defective plant. Should the EMPLOYER not so replace the defective plant the CONTRACTOR's extreme liability under this clause shall be limited to the repayment of all such sums paid by the EMPLOYER under the CONTRACT for such defective plant. 85 Indemnity 85.1 If any action is brought before a Court, Tribunal or any other Authority against the Employer or an officer or agent of the EMPLOYER, for the failure, omission or neglect on the part of the CONTRACTOR to perform any acts, matters, covenants or things under the CONTRACT, or damage or injury caused by the alleged omission or negligence on the part of the CONTRACTOR, his agents, representatives or his SUBCONTRACTOR's, or in connection with any claim based on lawful demands of SUB-CONTRACTOR's workmen suppliers or employees, the CONTRACTOR, shall in such cases indemnify and keep the EMPLOYER and/or their representatives harmless from all losses, damages, expenses or decrees arising out of such action. 86 Construction aids, equipments, tools & tackles: 86.1 CONTRACTOR shall be solely responsible for making available for executing the WORK, all requisite CONSTRUCTION EQUIPMENTS, Special Aids, Barges, Cranes and the like, all Tools, Tackles and Testing Equipment and Appliances, including imports of such equipment etc. As required. In case of import of the same the rates applicable for levying of Custom Duty on such Equipment, Tools, & Tackles and the duty drawback applicable thereon shall be ascertained by the CONTRACTOR from the concerned authorities of Government of India. It shall be clearly understood that EMPLOYER shall not in any way be responsible for arranging to obtain Custom Clearance and/or payment of any duties and/or duty draw backs etc. for such equipments so imported by the CONTRACTOR and the CONTRACTOR shall be fully responsible for all taxes, duties and documentation with regard to the same. Tenderer in his own interest may contact, for any clarifications in the matter, concerned agencies/Dept./Ministries of Govt. of India. All clarifications so obtained and interpretations thereof shall be solely the responsibility of the CONTRACTOR. SECTION-VI Certificates and Payments 87 Schedule of rates and payments: 87.1 i) CONTRACTOR'S REMUNERATION: The price to be paid by the EMPLOYER to CONTRACTOR for the whole of the WORK to be done and for the performance of all the obligations undertaken by the CONTRACTOR under the CONTRACT DOCUMENTS shall be ascertained by the application of the respective Schedule of Rates (the inclusive nature of which is more particularly defined by way of application but not of limitation, with the succeeding sub-clause of this clause) and (Sign & Seal of Bidder) Page 133 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II payment to be made accordingly for the WORK actually executed and approved by the ENGINEERIN- CHARGE. The sum so ascertained shall (excepting only as and to the extent expressly provided herein) constitute the sole and inclusive remuneration of the CONTRACTOR under the CONTRACT and no further or other payment whatsoever shall be or become due or payable to the CONTRACTOR under the CONTRACT. ii) SCHEDULE OF RATES TO BE INCLUSIVE: The prices/rates quoted by the CONTRACTOR shall remain firm till the issue of FINAL CERTIFICATE and shall not be subject to escalation. Schedule of Rates shall be deemed to include and cover all costs, expenses and liabilities of every description and all risks of every kind to be taken in executing, completing and handing over the WORK to the EMPLOYER by the CONTRACTOR. The CONTRACTOR shall be deemed to have known the nature, scope, magnitude and the extent of the WORK and materials required though the CONTRACT DOCUMENT may not fully and precisely furnish them. Tenderer's shall make such provision in the Schedule of Rates as he may consider necessary to cover the cost of such items of WORK and materials as may be reasonable and necessary to complete the WORK. The opinion of the ENGINEER-IN-CHARGE as to the items of WORK which are necessary and reasonable for COMPLETION OF WORK shall be final and binding on the CONTRACTOR, although the same may not be shown on or described specifically in CONTRACT DOCUMENTS. Generality of this present provision shall not be deemed to cut down or limit in any way because in certain cases it may and in other cases it may not be expressly stated that the CONTRACTOR shall do or perform a work or supply articles or perform services at his own cost or without addition of payment or without extra charge or words to the same effect or that it may be stated or not stated that the same are included in and covered by the Schedule of Rates. iii) SCHEDULE OF RATES TO COVER CONSTRUCTION EQUIPMENTS, MATERIALS, LABOUR ETC.: Without in any way limiting the provisions of the preceding sub-clause the Schedule of Rates shall be deemed to include and cover the cost of all construction equipment, temporary WORK (except as provided for herein), pumps, materials, labour, insurance, fuel, consumables, stores and appliances to be supplied by the CONTRACTOR and all other matters in connection with each item in the Schedule of Rates and the execution of the WORK or any portion thereof finished, complete in every respect and maintained as shown or described in the CONTRACT DOCUMENTS or as may be ordered in writing during the continuance of the CONTRACT. iv) SCHEDULE OF RATES TO COVER ROYALTIES, RENTS AND CLAIMS: The Schedule of Rates (i.e., VALUE OF CONTRACT) shall be deemed to include and cover the cost of all royalties and fees for the articles and processes, protected by letters, patent or otherwise incorporated in or used in connection with the WORK, also all royalties, rents and other payments in connection with obtaining materials of whatsoever kind for the WORK and shall include an indemnity to the EMPLOYER which the CONTRACTOR hereby gives against all actions, proceedings, claims, damages, costs and (Sign & Seal of Bidder) Page 134 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II expenses arising from the incorporation in or use on the WORK of any such articles, processes or materials, octroi or other municipal or local Board Charges, if levied on materials, equipment or machineries to be brought to site for use on WORK shall be borne by the CONTRACTOR. v) SCHEDULE OF RATES TO COVER TAXES AND DUTIES: No exemption or reduction of Customs Duties, Excise Duties, Sales Tax, Sales Tax on works Contract quay or any port dues, transport charges, stamp duties or Central or State Government or local Body or Municipal Taxes or duties, taxes or charges (from or of any other body), whatsoever, will be granted or obtained, all of which expenses shall be deemed to be included in and covered by the Schedule or Rates. The CONTRACTOR shall also obtain and pay for all permits or other privileges necessary to complete the WORK. vi) SCHEDULE OF RATES TO COVER RISKS OF DELAY: The Schedule of Rates shall be deemed to include and cover the risk of all possibilities of delay and interference with the CONTRACTOR's conduct of WORK which occur from any causes including orders of the EMPLOYER in the exercise of his power and on account of extension of time granted due to various reasons and for all other possible or probable causes of delay. vii) SCHEDULE OF RATES CANNOT BE ALTERED: For WORK under unit rate basis, no alteration will be allowed in the Schedule of Rates by reason of works or any part of them being modified, altered, extended, diminished or committed. The Schedule of Rates are fully inclusive of rates which have been fixed by the CONTRACTOR and agreed to by the EMPLOYER and cannot be altered. For lumpsum CONTRACTS, the payment will be made according to the WORK actually carried out, for which purpose an item wise, or work wise Schedule of Rates shall be furnished, suitable for evaluating the value of WORK done and preparing running account bill. Payment for any additional work which is not covered in the Schedule of Rates, shall only be released on issuance of change order. 88 Procedure for measurement and billing of work in progress: 88.1 BILLING PROCEDURE: Following procedures shall be adopted for billing of works executed by the CONTRACTOR. 88.1.1 All measurements shall be recorded in sextuplicate on standard measurement sheets supplied by EMPLOYER and submitted to EMPLOYER/CONSULTANT for scrutiny and passing. 88.1.2 EMPLOYER/CONSULTANT shall scrutinise and check the measurements recorded on the sheets and shall certify correctness of the same on the measurement sheets. 88.1.3 ENGINEER-IN-CHARGE shall pass the bills after carrying out the comprehensive checks in accordance with the terms and conditions of the CONTRACTS, within 7 days of submission of the bills, complete in all respects and send the same to the Employer to effect payment to the CONTRACTOR. 88.1.4 BGL shall make all endeavour to make payments of undisputed amount of the bills submitted based on the joint measurements within 15 (Fifteen) days from the date of certification by the Engineer-in-Charge. (Sign & Seal of Bidder) Page 135 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 88.1.5 Measurements shall be recorded as per the methods of measurement spelt out in EMPLOYER/CONSULTANT SPECIFICATIONS / CONTRACT DOCUMENT. EMPLOYER/CONSULTANT shall be fully responsible for checking the measurements quantitatively and qualitatively as recorded in the Measurement Books/ Bills. 88.1.6 While preparing the final bills overall measurements will not be taken again. Only volume of work executed since the last measured bill alongwith summary of final measurements will be considered for the final bill. However, a detailed check shall be made as to missing measurements and in case there are any missing items or measurements the same shall be recorded. 88.2 SECURED ADVANCE ON MATERIAL: Unless otherwise provided elsewhere in the tender, no `Secured Advance' on security of materials brought to site for execution of contracted items(s) shall be paid to the Contractor whatsoever. 88.3 DISPUTE IN MODE OF MEASUREMENT: In case of any dispute as to the mode of measurement not covered by the CONTRACT to be adopted for any item of WORK, mode of measurement as per latest Indian Standard Specifications shall be followed. 88.4 ROUNDING OF AMOUNTS: In calculating the amount of each item due to the CONTRACTOR in every certificate prepared for payment, sum of less than 50 paise shall be omitted and the total amount on each certificate shall be rounded off to the nearest rupees, i.e., sum of less than 50 paise shall be omitted and sums of 50 paise and more upto one rupee shall be reckoned as one rupee. 89 Lumpsum in tender: 89.1 The payment against any Lumpsum item shall be made only on completion of that item as per the provision of the CONTRACT after certification by ENGINEER-IN- CHARGE. 90 Running account payments to be regarded as advance: 90.1 All running account payments shall be regarded as payment by way of advance against the final payment only and not as payments for WORK actually done and completed and shall not preclude the requiring of bad, unsound and imperfect or unskilled work to be removed and taken away and reconstructed or re-erected or be considered as an admission of the due performance of the CONTRACT, or any part thereof, in this respect, or of the accurring of any claim by the CONTRACTOR, nor shall it conclude, determine or affect in any way the powers of the EMPLOYER under these conditions or any of them as to the final settlement and adjustment of the accounts or otherwise, or in any other way vary or affect the CONTRACT. The final bill shall be submitted by the CONTRACTOR within one month of the date of physical completion of the WORK, otherwise, the ENGINEER-IN-CHARGE's certificate of the measurement and of total amount payable for the WORK accordingly shall be final and binding on all parties 91 Notice of claims for additional payments: 91.1 Should the CONTRACTOR consider that he is entitled to any extra payment for any extra/additional WORKS or MATERIAL change in original SPECIFICATIONS (Sign & Seal of Bidder) Page 136 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II carried out by him in respect of WORK he shall forthwith give notice in writing to the ENGINEER-IN-CHARGE that he claims extra payment. Such notice shall be given to the ENGINEER-IN-CHARGE upon which CONTRACTOR bases such claims and such notice shall contain full particulars of the nature of such claim with full details of amount claimed. Irrespective of any provision in the CONTRACT to the contrary, the CONTRACTOR must intimate his intention to lodge claim on the EMPLOYER within 10 (ten) days of the commencement of happening of the event and quantify the claim within 30 (thirty) days, failing which the CONTRACTOR will lose his right to claim any compensation/reimbursement/damages etc. or refer the matter to arbitration. Failure on the part of CONTRACTOR to put forward any claim without the necessary particulars as above within the time above specified shall be an absolute waiver thereof. No omission by EMPLOYER to reject any such claim and no delay in dealing therewith shall be waiver by EMPLOYER of any of this rights in respect thereof. 91.2 ENGINEER-IN-CHARGE shall review such claims within a reasonably period of time and cause to discharge these in a manner considered appropriate after due deliberations thereon. However, CONTRACTOR shall be obliged to carry on with the WORK during the period in which his claims are under consideration by the EMPLOYER, irrespective of the outcome of such claims, where additional payments for WORKS considered extra are justifiable in accordance with the CONTRACT provisions, EMPLOYER shall arrange to release the same in the same manner as for normal WORK payments. Such of the extra works so admitted by EMPLOYER shall be governed by all the terms, conditions, stipulations and specifications as are applicable for the CONTRACT. The rates for extra works shall generally be the unit rates provided for in the CONTRACT. In the event unit rates for extra works so executed are not available as per CONTRACT, payments may either be released on day work basis for which daily/hourly rates for workmen and hourly rates for equipment rental shall apply, or on the unit rate for WORK executed shall be derived by interpolation/ extrapolation of unit rates already existing in the CONTRACT. In all the matters pertaining to applicability of rate and admittance of otherwise of an extra work claim of CONTRACTOR the decision of ENGINEER-IN-CHARGE shall be final and binding. 92 Payment of contractor's bill: 92.1 No payment shall be made for works estimated to cost less than Rs.10,000/- till the whole of the work shall have been completed and a certificate of completion given. But in case of works estimated to cost more than Rs.10,000/-, that CONTRACTOR on submitting the bill thereof be entitled to receive a monthly payment proportionate to the part thereof approved and passed by the ENGINEER-IN-CHARGE, whose certificate of such approval and passing of the sum so payable shall be final and conclusive against the CONTRACTOR. This payment will be made after making necessary corrections/deductions as stipulated elsewhere in the CONTRACT DOCUMENT for materials, Contract Performance Security,taxes etc. 92.2 Payment due to the CONTRACTOR shall be made by the EMPLOYER by Account Payee cheque forwarding the same to registered office or the notified office of the CONTRACTOR. In no case will EMPLOYER be responsible if the cheque is mislaid or misappropriated by unauthorised person/persons. In all cases, the CONTRACTOR shall present his bill duly pre-receipted on proper revenue stamp payment shall be made in Indian Currency. (Sign & Seal of Bidder) Page 137 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 92.3 In general payment of final bill shall be made to CONTRACTOR within 60 days of the submission of bill on joint measurements, after completion of all the obligations under the CONTRACT. 93 Receipt for payment: 93.1 Receipt for payment made on account of work when executed by a firm, must be signed by a person holding due power of attorney in this respect on behalf of the CONTRACTOR, except when the CONTRACTOR's are described in their tender as a limited company in which case the receipts must be signed in the name of the company by one of its principal officers or by some other person having authority to give effectual receipt for the company. 94 Completion certificate: 94.1 APPLICATION FOR COMPLETION CERTIFICATE: When the CONTRACTOR fulfils his obligation under Clause 81.1 he shall be eligible to apply for COMPLETION CERTIFICATE. The ENGINEER-IN-CHARGE shall normally issue to the CONTRACTOR the COMPLETION CERTIFICATE within one month after receiving any application therefore from the CONTRACTOR after verifying from the completion documents and satisfying himself that the WORK has been completed in accordance with and as set out in the construction and erection drawings, and the CONTRACT DOCUMENTS. The CONTRACTOR, after obtaining the COMPLETION CERTIFICATE, is eligible to present the final bill for the WORK executed by him under the terms of CONTRACT. 94.2 COMPLETION CERTIFICATE: Within one month of the completion of the WORK in all respects, the CONTRACTOR shall be furnished with a certificate by the ENGINEER-IN- CHARGE of such completion, but no certificate shall be given nor shall the WORK be deemed to have been executed until all scaffolding, surplus materials and rubbish is cleared off the SITE completely nor until the WORK shall have been measured by the ENGINEER-IN-CHARGE whose measurement shall be binding and conclusive. The WORKS will not be considered as complete and taken over by the EMPLOYER, until all the temporary works, labour and staff colonies are cleared to the satisfaction of the ENGINEER-IN-CHARGE. If the CONTRACTOR fails to comply with the requirements of this clause on or before the date fixed for the completion of the WORK, the ENGINEER-IN-CHARGE may at the expense of the CONTRACTOR remove such scaffolding, surplus materials and rubbish and dispose off the same as he thinks fit and clean off such dirt as aforesaid, and the CONTRACTOR shall forthwith pay the amount of all expenses so incurred and shall have no claim in respect of any such scaffolding or surplus materials as aforesaid except for any sum actually realised by the sale thereof. 94.3 COMPLETION CERTIFICATE DOCUMENTS: For the purpose of Clause 94.0 the following documents will be deemed to form the completion documents: i) The technical documents according to which the WORK was carried out. ii) Six (6) sets of construction drawings showing therein the modification and correction made during the course of execution and signed by the ENGINEER-IN-CHARGE. (Sign & Seal of Bidder) Page 138 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II iii) COMPLETION CERTIFICATE for `embedded' and `covered' up work. iv) Certificates of final levels as set out for various works. v) Certificates of tests performed for various WORKS. vi) Material appropriation, Statement for the materials issued by the EMPLOYER for the WORK and list of surplus materials returned to the EMPLOYER's store duly supported by necessary documents. 95 Final decision and final certificate: 95.1 Upon expiry of the period of liability and subject to the ENGINEER-IN-CHARGE being satisfied that the WORKS have been duly maintained by the CONTRACTOR during monsoon or such period as hereinbefore provided in Clause 80 & 81 and that the CONTRACTOR has in all respect duly made-up any subsidence and performed all his obligations under the CONTRACT, the ENGINEER-IN- CHARGE shall (without prejudice to the rights of the EMPLOYER to retain the provisions of relevant Clause hereof) otherwise give a certificate herein referred to as the FINAL CERTIFICATE to that effect and the CONTRACTOR shall not be considered to have fulfilled the whole of his obligations under CONTRACT until FINAL CERTIFICATE shall have been given by the ENGINEER-IN- CHARGE notwithstanding any previous entry upon the WORK and taking possession, working or using of the same or any part thereof by the EMPLOYER. 96 Certificate and payments on evidence of completion: 96.1 Except the FINAL CERTIFICATE, no other certificates or payments against a certificate or on general account shall be taken to be an admission by the EMPLOYER of the due performance of the CONTRACT or any part thereof or of occupancy or validity of any claim by the CONTRACTOR. 97 Deductions from the contract price: 97.1 All costs, damages or expenses which EMPLOYER may have paid or incurred, which under the provisions of the CONTRACT, the CONTRACTOR is liable/will be liable, will be claimed by the EMPLOYER. All such claims shall be billed by the EMPLOYER to the CONTRACTOR regularly as and when they fall due. Such claims shall be paid by the CONTRACTOR within 15 (fifteen) days of the receipt of the corresponding bills and if not paid by the CONTRACTOR within the said period, the EMPLOYER may, then, deduct the amount from any moneys due i.e., Contract Performance Security or becoming due to the CONTRACTOR under the CONTRACT or may be recovered by actions of law or otherwise, if the CONTRACTOR fails to satisfy the EMPLOYER of such claims. SECTION-VII Taxes and Insurance 98 Taxes, Duties, Octroi etc: 98.1 The CONTRACTOR agrees to and does hereby accept full and exclusive liability for the payment of any and all Taxes, Duties, including Excise duty, octroi etc. now or hereafter imposed, increased, modified, all the sales taxes, duties, octrois etc. now in force and hereafter increased, imposed or modified, from time to time in respect of WORKS and materials and all contributions and taxes for unemployment compensation, insurance and old age pensions or annuities now or hereafter imposed (Sign & Seal of Bidder) Page 139 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II by any Central or State Government authorities which are imposed with respect to or covered by the wages, salaries, or other compensations paid to the persons employed by the CONTRACTOR and the CONTRACTOR shall be responsible for the compliance of all SUB-CONTRACTORS, with all applicable Central, State, Municipal and local law and regulation and requirement of any Central, State or local Government agency or authority. CONTRACTOR further agrees to defend, indemnify and hold EMPLOYER harmless from any liability or penalty which may be imposed by the Central, State or Local authorities by reason or any violation by CONTRACTOR or SUB-CONTRACTOR of such laws, suits or proceedings that may be brought against the EMPLOYER arising under, growing out of, or by reason of the work provided for by this CONTRACT, by third parties, or by Central or State Government authority or any administrative sub-division thereof. Tax deductions will be made as per the rules and regulations in force in accordance with acts prevailing from time to time. 99 Sales tax/turnover tax: 99.1 Tenderer should quote all inclusive prices including the liability of Sales Tax/Turnover Tax whether on the works contract as a whole or in respect of bought out components used by the CONTRACTOR in execution of the CONTRACT. EMPLOYER shall not be responsible for any such liability of the CONTRACTOR in respect of this CONTRACT. 100 Statutory variations 100.1 Tenderer should quote prices inclusive of excise-duty and sales tax applicable on finished product. Any statutory variations in Excise Duty and sales tax on finished product during the contractual completion period, shall be to the Employer's account for which the Contractor will furnish documentary evidence(s) in support of their claims to BGL. However, any increase in the rate of these taxes and duties (E.D. and S.T.) beyond the contractual completion period shall be to Contractor's account and any decrease shall be passed on to BGL. 101 Insurance: 101.1 GENERAL CONTRACTOR shall at his own expense arrange secure and maintain insurance with reputable insurance companies to the satisfaction of the EMPLOYER as follows: CONTRACTOR at his cost shall arrange, secure and maintain insurance as may be necessary and to its full value for all such amounts to protect the WORKS in progress from time to time and the interest of EMPLOYER against all risks as detailed herein. The form and the limit of such insurance, as defined here in together with the under works thereof in each case should be as acceptable to the EMPLOYER. However, irrespective of work acceptance the responsibility to maintain adequate insurance coverage at all times during the period of CONTRACT shall be that of CONTRACTOR alone. CONTRACTOR's failure in this regard shall not relieve him of any of his responsibilities and obligations under CONTRACT. Any loss or damage to the equipment, during ocean transportation, port/custom clearance, inland and port handling, inland transportation, storage, erection and commissioning till such time the WORK is taken over by EMPLOYER, shall be to the account of CONTRACTOR. (Sign & Seal of Bidder) Page 140 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II CONTRACTOR shall be responsible for preferring of all claims and make good for the damage or loss by way of repairs and/or replacement of the parts of the Work damaged or lost. CONTRACTOR shall provide the EMPLOYER with a copy of all insurance policies and documents taken out by him in pursuance of the CONTRACT. Such copies of document shall be submitted to the EMPLOYER immediately upon the CONTRACTOR having taken such insurance coverage. CONTRACTOR shall also inform the EMPLOYER at least 60(Sixty) days in advance regarding the expiry cancellation and/or changes in any of such documents and ensure revalidation/renewal etc., as may be necessary well in time. Statutory clearances, if any, in respect of foreign supply required for the purpose of replacement of equipment lost in transit and/or during erection, shall be made available by the EMPLOYER. CONTRACTOR shall, however, be responsible for obtaining requisite licences, port clearances and other formalities relating to such import. The risks that are to be covered under the insurance shall include, but not be limited to the loss or damage in handling, transit, theft, pilferage, riot, civil commotion, weather conditions, accidents of all kinds, fire, war risk (during ocean transportation only) etc. The scope of such insurance shall cover the entire value of supplies of equipments, plants and materials to be imported from time to time. All costs on account of insurance liabilities covered under CONTRACT will be to CONTRACTOR's account and will be included in VALUE OF CONTRACT. However, the EMPLOYER may from time to time, during the currency of the CONTRACT, ask the CONTRACTOR in writing to limit the insurance coverage risk and in such a case, the parties to the CONTRACT will agree for a mutual settlement, for reduction in VALUE OF CONTRACT to the extent of reduced premium amounts. CONTRACTOR as far as possible shall cover insurance with Indian Insurance Companies, including marine Insurance during ocean transportation. i) EMPLOYEES STATE INSURANCE ACT: The CONTRACTOR agrees to and does hereby accept full and exclusive liability for the compliance with all obligations imposed by the Employee State Insurance Act 1948 and the CONTRACTOR further agrees to defend, indemnify and hold EMPLOYER harmless for any liability or penalty which may be imposed by the Central, State or Local authority by reason of any asserted violation by CONTRACTOR or SUB-CONTRACTOR of the Employees' State Insurance Act, 1948, and also from all claims, suits or proceeding that may be brought against the EMPLOYER arising under, growing out of or by reasons of the work provided for by this CONTRACTOR, by third parties or by Central or State Government authority or any political sub- division thereof. The CONTRACTOR agrees to fill in with the Employee's State Insurance Corporation, the Declaration Forms, and all forms which may be required in respect of the CONTRACTOR's or SUB- CONTRACTOR's employees, who are employed in the WORK provided for or those covered by ESI from time to time under the Agreement. The CONTRACTOR shall deduct and secure the agreement of the SUB- CONTRACTOR to deduct the employee's contribution as per the first schedule of the Employee's State Insurance Act from wages and affix the Employees Contribution Card at wages payment intervals. The CONTRACTOR shall remit and secure the agreement of SUB- CONTRACTOR to remit to the State Bank of India, Employee's State (Sign & Seal of Bidder) Page 141 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II Insurance Corporation Account, the Employee's contribution as required by the Act. The CONTRACTOR agrees to maintain all cards and Records as required under the Act in respect of employees and payments and the CONTRACTOR shall secure the agreement of the SUBCONTRACTOR to maintain such records. Any expenses incurred for the contributions, making contributions or maintaining records shall be to the CONTRACTOR's or SUB-CONTRACTOR's account. The EMPLOYER shall retain such sum as may be necessary from the total VALUE OF CONTRACT until the CONTRACTOR shall furnish satisfactory proof that all contributions as required by the Employees State Insurance Act, 1948, have been paid. This will be pending on the CONTRACTOR when the ESI Act is extended to the place of work. ii) WORKMEN COMPENSATION AND EMPLOYER'S LIABILITY INSURANCE: Insurance shall be affected for all the CONTRACTOR's employees engaged in the performance of this CONTRACT. If any of the work is sublet, the CONTRACTOR shall require the SUB-CONTRACTOR to provide workman's Compensation and employer's liability insurance for the later's employees if such employees are not covered under the CONTRACTOR's Insurance. iii) ACCIDENT OR INJURY TO WORKMEN: The EMPLOYER shall not be liable for or in respect of any damages or compensation payable at law in respect or in consequence of any accident or injury to any workman or other person in the Employment of the CONTRACTOR or any SUB-CONTRACTOR save and except an accident or injury resulting from any act or default of the EMPLOYER, his agents or servants and the CONTRACTOR shall indemnify and keep indemnified the EMPLOYER against all such damages and compensation (save and except and aforesaid) and against all claims, demands, proceeding, costs, charges and expenses, whatsoever in respect or in relation thereto. iv) TRANSIT INSURANCE In respect of all items to be transported by the CONTRACTOR to the SITE of WORK, the cost of transit insurance should be borne by the CONTRACTOR and the quoted price shall be inclusive of this cost. V) COMPREHENSIVE AUTOMOBILE INSURANCE This insurance shall be in such a form as to protect the Contractor against all claims for injuries, disability, disease and death to members of public including EMPLOYER‟s men and damage to the property of others arising from the use of motor vehicles during on or off the `site‟operations, irrespective of the Employership of such vehicles. VI) COMPREHENSIVE GENERAL LIABILITY INSURANCE a) This insurance shall protect the Contractor against all claims arising from injuries, disabilities, disease or death of member of public or damage to property of others due to any act or omission on the part of the Contractor, his agents, his employees, his representatives and Sub-Contractor‟s or from riots, strikes and civil commotion. b) Contractor shall take suitable Group Personal Accident Insurance Cover for taking care of injury, damage or any other risks in respect of his (Sign & Seal of Bidder) Page 142 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II Engineers and other Supervisory staff who are not covered under Employees State Insurance Act. c) The policy shall cover third party liability. The third party (liability shall cover the loss/ disablement of human life (person not belonging to the Contractor) and also cover the risk of damage to others materials/ equipment/ properties during construction, erection and commissioning at site. The value of third party liability for compensation for loss of human life or partial/full disablement shall be of required statutory value but not less than Rs. 2 lakhs per death, Rs. 1.5 lakhs per full disablement and Rs. 1 lakh per partial disablement and shall nevertheless cover such compensation as may be awarded by Court by Law in India and cover for damage to others equipment/ property as approved by the Purchaser. However, third party risk shall be maximum to Rs. 10(ten) lakhs to death. d) The Contractor shall also arrange suitable insurance to cover damage, loss, accidents, risks etc., in respect of all his plant, equipments and machinery, erection tools & tackles and all other temporary attachments brought by him at site to execute the work. e) The Contractor shall take out insurance policy in the joint name of EMPLOYER and Contractor from one or more nationalised insurance company from any branch office at Project site. f) Any such insurance requirements as are hereby established as the minimum policies and coverages which Contractor must secure and keep in force must be complied with, Contrator shall at all times be free to obtain additional or increased coverages at Contractor‟s sole expenses. vii) ANY OTHER INSURANCE REQUIRED UNDER LAW OR REGULATIONS OR BY EMPLOYER: CONTRACTOR shall also carry and maintain any and all other insurance(s) which he may be required under any law or regulation from time to time without any extra cost to EMPLOYER. He shall also carry and maintain any other insurance which may be required by the EMPLOYER. 102 Damage to Property or to any Person or any Third Party 102.1 i) CONTRACTOR shall be responsible for making good to the satisfaction of the EMPLOYER any loss or any damage to structures and properties belonging to the EMPLOYER or being executed or procured or being procured by the EMPLOYER or of other agencies within in the premises of all the work of the EMPLOYER, if such loss or damage is due to fault and/or the negligence or willful acts or omission of the CONTRACTOR, his employees, agents, representatives or SUB-CONTRACTORs. ii) The CONTRACTOR shall take sufficient care in moving his plants, equipments and materials from one place to another so that they do not cause any damage to any person or to the property of the EMPLOYER or any third party including overhead and underground cables and in the event of any damage resulting to the property of the EMPLOYER or of a third party during the movement of the aforesaid plant, equipment or materials the cost of such damages including eventual loss of production, operation or services in any (Sign & Seal of Bidder) Page 143 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II plant or establishment as estimated by the EMPLOYER or ascertained or demanded by the third party shall be borne by the CONTRACTOR. Third party liability risk shall be Rupees One lakh for single accident and limited to Rupees Ten lakhs. ii) The CONTRACTOR shall indemnify and keep the EMPLOYER harmless of all claims for damages to property other than EMPLOYER's property arising under or by reason of this agreement, if such claims result from the fault and/or negligence or willful acts or omission of the CONTRACTOR, his employees, agents, representative of SUB-CONTRACTOR. SECTION-VIII Labour Laws 103 Labour laws: 103.1 i) No labour below the age of 18 (eighteen) years shall be employed on the WORK. ii) The CONTRACTOR shall not pay less than what is provided under law to labourers engaged by him on the WORK. iii) The CONTRACTOR shall at his expense comply with all labour laws and keep the EMPLOYER indemnified in respect thereof. iv) The CONTRACTOR shall pay equal wages for men and women in accordance with applicable labour laws. v) If the CONTRACTOR is covered under the Contract labour (Regulation and Abolition) Act, he shall obtain a licence from licensing authority (i.e. office of the labour commissioner) by payment of necessary prescribed fee and the deposit, if any, before starting the WORK under the CONTRACT. Such fee/deposit shall be borne by the CONTRACTOR. vi) The CONTRACTOR shall employ labour in sufficient numbers either directly or through SUB- CONTRACTOR's to maintain the required rate of progress and of quality to ensure workmanship of the degree specified in the CONTRACT and to the satisfaction of the ENGINEER-IN-CHARGE. vii) The CONTRACTOR shall furnish to the ENGINEER-INCHARGE the distribution return of the number and description, by trades of the work people employed on the works. The CONTRACTOR shall also submit on the 4th and 19th of every month to the ENGINEER-IN-CHARGE a true statement showing in respect of the second half of the preceding month and the first half of the current month (1) the accidents that occurred during the said fortnight showing the circumstances under which they happened and the extent of damage and injury caused by them and (2) the number of female workers who have been allowed Maternity Benefit as provided in the Maternity Benefit Act 1961 on Rules made thereunder and the amount paid to them. viii) The CONTRACTOR shall comply with the provisions of the payment of Wage Act 1936, Employee Provident Fund Act 1952, Minimum Wages Act 1948, Employers Liability Act 1938. Workmen's Compensation Act 1923, Industrial Disputes Act 1947, the Maternity Benefit Act 1961 and Contract Labour Regulation and Abolition Act 1970, Employment of Children Act 1938 or any modifications thereof or any other law relating thereto and rules made thereunder from time to time. (Sign & Seal of Bidder) Page 144 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II ix) The ENGINEER-IN-CHARGE shall on a report having been made by an Inspecting Officer as defined in Contract Labour (Regulation and Abolition) Act 1970 have the power to deduct from the money due to the CONTRACTOR any sum required or estimated to be required for making good the loss suffered by a worker or workers by reason of non- fulfillment of the Conditions of the Contract for the benefit of workers, non-payment of wages or of deductions made from his or their wages which are not justified by the terms of the Contract or non-observance of the said regulations. x) The CONTRACTOR shall indemnify the EMPLOYER against any payments to be made under and for the observance of the provisions of the aforesaid Acts without prejudice to his right to obtain indemnity from his SUB- CONTRACTOR's. In the event of the CONTRACTOR committing a default or breach of any of the provisions of the aforesaid Acts as amended from time to time, of furnishing any information or submitting or filling and Form/ Register/ Slip under the provisions of these Acts which is materially incorrect then on the report of the inspecting Officers, the CONTRACTOR shall without prejudice to any other liability pay to the EMPLOYER a sum not exceeding Rs.50.00 as Liquidated Damages for every default, breach or furnishing, making, submitting, filling materially incorrect statement as may be fixed by the ENGINEER-IN- CHARGE and in the event of the CONTRACTOR's default continuing in this respect, the Liquidated Damages may be enhanced to Rs.50.00 per day for each day of default subject to a maximum of one percent of the estimated cost of the WORK put to tender. The ENGINEER-IN-CHARGE shall deduct such amount from bills or Contract Performance Security of the CONTRACTOR and credit the same to the Welfare Fund constitute under these acts. The decision of the ENGINEER- IN-CHARGE in this respect shall be final and binding. 104 Implementation of apprentices act, 1961: 104.1 The CONTRACTOR shall comply with the provisions of the Apprentices Act, 1961 and the Rules and Orders issued thereunder from time to time. If he fails to do so, his failure will be a breach of the CONTRACT and the ENGINEER-IN-CHARGE may, at his discretion, cancel the CONTRACT. The CONTRACTOR shall also be liable for any pecuniary liability arising on account of any violation by him of the provisions, of the Act. 105 Contractor to indemnify the employer: i) The CONTRACTOR shall indemnify the EMPLOYER and every member, office and employee of the EMPLOYER, also the ENGINEER-IN-CHARGE and his staff against all actions, proceedings, claims, demands, costs and expenses whatsoever arising out of or in connection with the matters referred to in Clause 102.0 and elsewhere and all actions, proceedings, claims, demands, costs and expenses which may be made against the EMPLOYER for or in respect of or arising out of any failure by the CONTRACTOR in the performance of his obligations under the CONTRACT DOCUMENT. The EMPLOYER shall not be liable for or in respect of or arising out of any failure by the CONTRACTOR in the performance of his obligations under the (Sign & Seal of Bidder) Page 145 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II CONTRACT DOCUMENT. The EMPLOYER shall not be liable for or in respect of any demand or compensation payable by law in respect or in consequence of any accident or injury to any workmen or other person. In the employment of the CONTRACTOR or his SUB-CONTRACTOR the CONTRACTOR shall indemnify and keep indemnified the EMPLOYER against all such damages and compensations and against all claims, damages, proceedings, costs, charges and expenses whatsoever in respect thereof or in relation thereto. ii) PAYMENT OF CLAIMS AND DAMAGES: Should the EMPLOYER have to pay any money in respect of such claims or demands as aforesaid the amount so paid and the costs incurred by the EMPLOYER shall be charged to and paid by the CONTRACTOR and the CONTRACTOR shall not be at liberty to dispute or question the right of the EMPLOYER to make such payments notwithstanding the same, may have been made without the consent or authority or in law or otherwise to the contrary. iii) In every case in which by virtue of the provisions of Section 12, Sub-section (i) of workmen's compensation Act, 1923 or other applicable provision of Workmen Compensation Act or any other Act, the EMPLOYER is obliged to pay compensation to a workman employed by the CONTRACTOR in execution of the WORK, the EMPLOYER will recover from the CONTRACTOR the amount of the compensation so paid, and without prejudice to the rights of EMPLOYER under Section 12, Sub- section (2) of the said act, EMPLOYER shall be at liberty to recover such amount or any part thereof by deducting it from the Contract Performance Security or from any sum due to the CONTRACTOR whether under this CONTRACT or otherwise. The EMPLOYER shall not be bound to contest any claim made under Section 12, Sub- section (i) of the said act, except on the written request of the CONTRACTOR and upon his giving to the EMPLOYER full security for all costs for which the EMPLOYER might become liable in consequence of contesting such claim. 106 Health and sanitary arrangements for workers: 106.1 In respect of all labour directly or indirectly employed in the WORKS for the performance of the CONTRACTOR's part of this agreement, the CONTRACTOR shall comply with or cause to be complied with all the rules and regulations of the local sanitary and other authorities or as framed by the EMPLOYER from time to time for the protection of health and sanitary arrangements for all workers. 106.2 The CONTRACTOR shall provide in the labour colony all amenities such as electricity, water and other sanitary and health arrangements. The CONTRACTOR shall also provide necessary surface transportation to the place of work and back to the colony for their personnel accommodated in the labour colony. SECTION-IX Applicable Laws and Settlement of Disputes 107 Arbitration: 107.1 Unless otherwise specified, the matters where decision of the Engineer-in- Charge is deemed to be final and binding as provided in the Agreement and the issues/disputes (Sign & Seal of Bidder) Page 146 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II which cannot be mutually resolved within a reasonable time, all disputes shall be referred to arbitration by Sole Arbitrator. The Employer Bhagyanagar Gas Limited shall suggest a panel of three independent and distinguished persons to the bidder/contractor/supplier/buyer (as the case may be) to select any one among them to act as the Sole Arbitrator. In the event of failure of the other parties to select the Sole Arbitrator within 30 days from the receipt of the communication suggesting the panel of arbitrators, the right of selection of the sole arbitrator by the other party shall stand forfeited and the EMPLOYER (BGL) shall have discretion to proceed with the appointment of the Sole Arbitrator. The decision of Employer on the appointment of the sole arbitrator shall be final and binding on the parties. The award of sole arbitrator shall be final and binding on the parties and unless directed/awarded otherwise by the sole arbitrator, the cost of arbitration proceedings shall be shared equally by the parties. The Arbitration proceedings shall be in English language and venue shall be Hyderabad, India. Subject to the above, the provisions of (Indian) Arbitration & Conciliation ACT 1996 and the Rules framed there under shall be applicable. All matter relating to this contract are subject to the exclusive jurisdiction of the court situated in Hyderabad. Bidders/suppliers/contractors may please note that the Arbitration & Conciliation Act 1996 was enacted by the Indian Parliament and is based on United Nations Commission on International Trade Law (UNCITRAL model law), which were prepared after extensive consultation with Arbitral Institutions and centers of International Commercial Arbitration. The United Nations General Assembly vide resolution 31/98 adopted the UNCITRAL Arbitration rules on 15 December 1976. 107.2 FOR THE SETTLEMENT OF DISPUTES BETWEEN GOVERNMENT DEPARTMENT AND ANOTHER AND ONE GOVERNMENT DEPARTMENT AND PUBLIC ENTERPRISE AND ONE PUBLIC ENTERPRISE AND ANOTHER THE ARBITRATION SHALL BE AS FOLLOWS: "In the event of any dispute or difference between the parties hereto, such dispute or difference shall be resolved amicably by mutual consultation or through the good offices of empowered agencies of the Government. If such resolution is not possible, then, the unresolved dispute or difference shall be referred to arbitration of an arbitrator to be nominated by Secretary, Department of Legal Affairs ("Law Secretary") in terms of the Office Memorandum No.55/3/1/75-CF, dated the 19th December 1975 issued by the Cabinet Secretariat (Department of Cabinet Affairs), as modified from time to time. The Arbitration Act 1940 (10 of 1940) shall not be applicable to the arbitration under this clause. The award of the Arbitrator shall be binding upon parties to the dispute. Provided, however, any party aggrieved by such award may make a further reference for setting aside or revision of the award to Law Secretary whose decision shall bind the parties finally and conclusively. 108 Jurisdiction: The CONTRACT shall be governed by and constructed according to the laws in force in INDIA. The CONTRACTOR hereby submits to the jurisdiction of the Courts situated at HYDERABAD for the purposes of disputes, actions and proceedings arising out of the CONTRACT, the courts at HYDERABAD only will have the jurisdiction to hear and decide such disputed, actions and proceedings. (Sign & Seal of Bidder) Page 147 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED SECTION-X Safety Codes 109 General: Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 109.1 CONTRACTOR shall adhere to safe construction practice and guard against hazardous, and unsafe working conditions and shall comply with EMPLOYER's safety rules as set forth herein. Prior to start of construction, CONTRACTOR will be furnished copies of EMPLOYER's "Safety Code" for information and guidance, if it has been prepared. 110 Safety regulations: 110.1 i) In respect of all labour, directly employed in the WORK for the performance of CONTRACTOR's part of this agreement, the CONTRACTOR shall at his own expense arrange for all the safety provisions as per safety codes of C.P.W.D., Indian Standards Institution. The Electricity Act, The Mines Act and such other acts as applicable. ii) The CONTRACTOR shall observe and abide by all fire and safety regulations of the EMPLOYER. Before starting construction work CONTRACTOR shall consult with EMPLOYER's safety Engineers or ENGINEER- IN-CHARGE and must make good to the satisfaction of the EMPLOYER any loss or damage due to fire to any portion of the work done or to be done under this agreement or to any of the EMPLOYER's existing property. 111 First aid and industrial injuries: 111.0 i) CONTRACTOR shall maintain first aid facilities for its employees and those of its SUB-CONTRACTOR. ii) CONTRACTOR shall make outside arrangements for ambulance service and for the treatment of industrial injuries. Names of those providing these services shall be furnished to EMPLOYER prior to start of construction and their telephone numbers shall be prominently posted in CONTRACTOR's field office. iv) All critical industrial injuries shall be reported promptly to EMPLOYER, and a copy of CONTRACTOR's report covering each personal injury requiring the attention of a physician shall be furnished to the EMPLOYER. 112 General rules: 112.0 Smoking within the battery area, tank farm or dock limits is strictly prohibited. Violators of the no smoking rules shall be discharged immediately. 113 Contractor's barricades: 113.0 i) CONTRACTOR shall erect and maintain barricades required in connection with his operation to guard or protect:- a) Excavations b) Hoisting Areas. (Sign & Seal of Bidder) Page 148 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II c) Areas adjudged hazardous by CONTRACTOR's or EMPLOYER's inspectors. d) EMPLOYER's existing property subject to damage by CONTRACTOR's Operations. e) Rail Road unloading spots. ii) CONTRACTOR's employees and those of his SUBCONTRACTOR's shall become acquainted with EMPLOYER's barricading practice and shall respect the provisions thereof. iii) Barricades and hazardous areas adjacent to, but not located in normal routes of travel shall be marked by red flasher lanterns at nights. 114 Scaffolding: 114.1 i) Suitable scaffolding should be provided for workmen for all works that cannot safely be done from the ground or from solid construction except such short period work as can be done safely from ladders. When a ladder is used an extra Mazdoor shall be engaged for holding the ladder and if the ladder is used for carrying material as well, suitable footholds and handholds shall be provided on the ladder and the ladder shall be given an inclination not steeper than 1 in 4 (1 horizontal and 4 vertical). ii) Scaffolding or staging more than 4 metres above the ground or floor, swing suspended from an overhead support or erected with stationary support shall have a guard rail properly attached, bolted, braced and otherwise retarded at least one metre high above the floor or platform of such scaffolding or staging and extending along the entire length of the outside and ends thereof with only such openings as may be necessary for the delivery of materials. Such scaffolding or staging shall be so fastened as to prevent it from swaying from the building or structure. iii) Working platform, gangway and stairway should be so constructed that they should not sag unduly or unequally and if the height of platform of the gangway or the stairway is more than 4 metres above the ground level or floor level, they should be closely boarded, should have adequate width and should be suitably fastened as in ii) above. iv) Every opening in the floor of a building or in a working platform shall be provided with suitable means to prevent the fall of persons or materials by providing suitable fencing of railing whose minimum heights shall be 1 metre. v) Safe-means of access shall be provided to all working platforms and other working places, every ladder shall be securely fixed. No portable single ladder shall be over 9 metres in length while the width between side rails in rung ladder shall in no case be less than 30 cms for ladder upto and including 3 metres in length. For longer ladder this width should be increased 5mm for each additional foot of length. Uniform steps spacing shall not exceed 30 cms. Adequate precautions shall be taken to prevent danger from electrical equipment. No materials on any of the sites or work shall be so stacked or placed to cause danger or inconvenience to any person or public. The CONTRACTOR shall also provide all necessary fencing and lights to protect the workers and staff from accidents, and shall be bound to bear the expenses of defense of every suit, action or other proceeding of law that may be brought (Sign & Seal of Bidder) Page 149 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II by any person for injury sustained owing to neglect of the above precautions and pay any damages and costs which may be awarded in any such suit or action or proceeding to any such person or which may with the consent of the CONTRACTOR be paid to compromise any claim by any such person. 115 Excavation and trenching: 115.1 All trenches 1.2 meters or more in depth shall at all times be supplied with at least one ladder for each 50 meters length or fraction thereof. Ladder shall be extended from bottom of the trenches to at least 1 meter above the surface of the ground. The sides of the trenches which are 1.5M in depth shall be stepped back to give suitable slope or securely held by timber bracing, so as to avoid the danger of sides to collapse. The excavated materials shall not be placed within 1.5 meters of the edge of the trench or half of the trench width whichever is more. Cutting shall be done from top to bottom. Under no circumstances undermining or under-cutting shall be done. 116 Demolition/general safety: 116.1 i) Before any demolition work is commenced and also during the progress of the demolition work a) All roads and open areas adjacent to the work site shall either be closed or suitably protected. b) No electric cable or apparatus which is liable to be a source of danger shall remain electrically charged. c) All practical steps shall be taken to prevent danger to persons employed from risk of fire or explosion or flooding. No floor, roof or other part of the building shall be so overloaded with debris or materials as to render it unsafe. ii) All necessary personal safety equipment as considered adequate by the ENGINEER-IN-CHARGE should be kept available for the use of the persons employed on the SITE and maintained in condition suitable for immediate use, and the CONTRACTOR shall take adequate steps to ensure proper use of equipment by those concerned. a) Workers employed on mixing asphaltic materials, cement and lime mortars shall be provided with protective footwear and protective gloves. b) Those engaged in white washing and mixing or stacking or cement bags or any material which are injurious to the eyes be provided with protective goggles. c) Those engaged in welding and cutting works shall be provided with protective face & eye shield, hand gloves, etc. d) Stone breakers shall be provided with protective goggles and protective clothing and seated at sufficiently safe intervals. e) When workers are employed in sewers and manholes, which are in use, the CONTRACTOR shall ensure that the manhole covers are opened and are ventilated at least for an hour before the workers are allowed to get into the manholes, and the manholes so opened shall be cordoned off with suitable railing and provided with warning signals or board to prevent accident to the public. (Sign & Seal of Bidder) Page 150 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II f) The CONTRACTOR shall not employ men below the age of 18 years and women on the work of painting with products containing lead in any form. Wherever men above the age of 18 years are employed on the work of lead painting, the following precautions should be taken. 1) No paint containing lead or lead product shall be used except in the form of paste or readymade paint. 2) Suitable face masks should be supplied for use by the workers when paint is applied in the form of spray or a surface having lead paint dry rubbed and scrapped. 3) Overalls shall be supplied by the CONTRACTOR to the workmen and adequate facilities shall be provided to enable the working painters to wash them during and on cessation of work. iii) When the work is done near any place where there is risk of drowning, all necessary safety equipment should be provided and kept ready for use and all necessary steps taken for prompt rescue of any person in danger and adequate provision should be made for prompt first aid treatment of all injuries likely to be sustained during the course of the work. iv) Use of hoisting machines and tackles including their attachments, anchorage and supports shall conform to the following standards or conditions: a) These shall be of good mechanical construction, sound materials and adequate strength and free from patent defect and shall be kept in good working order. b) Every rope used in hoisting or lowering materials or as means of suspension shall be of durable quality and adequate strength and free from patent defects. c) Every crane driver or hoisting appliance operator shall be properly qualified and no person under the age of 21 years should be in charge of any hoisting machine including any scaffolding, winch or give signals to the operator. d) In case of every hoisting machine and of every chain ring hook, shackle, swivel, and pulley block used in hoisting or lowering or as means of suspension, the safe working load shall be ascertained by adequate means. Every hoisting machine and all gears referred to above shall be plainly marked with the safe working load of the conditions under which it is applicable and the same shall be clearly indicated. No part of any machine or any gear referred to above in this paragraph shall be loaded beyond safe working load except for the purpose of testing. e) In case of departmental machine, the safe working load shall be notified by the ENGINEER- IN-CHARGE. As regards CONTRACTOR's machines, the CONTRACTOR shall notify the safe working load of the machine to the ENGINEER-IN-CHARGE whenever he brings any machinery to SITE of WORK and get it verified by the Engineer concerned. v) Motors, gears, transmission lines, electric wiring and other dangerous parts of hoisting appliances should be provided with efficient safeguards. Hoisting appliances should be provided with such means as to reduce to minimum the (Sign & Seal of Bidder) Page 151 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II accidental descent of the load, adequate precautions should be taken to reduce the minimum risk of any part or parts of a suspended load becoming accidentally displaced. When workers are employed on electrical installations which are already energized, insulating mats, wearing apparel, such as gloves, sleeves, and boots as may be necessary should be provided. The workers shall not wear any rings, watches and carry keys or other materials which are good conductors of electricity. vi) All scaffolds, ladders and other safety devices mentioned or described herein shall be maintained in safe conditions and no scaffolds, ladder or equipment shall be altered or removed while it is in use. Adequate washing facilities should be provided at or near places of work. vii) These safety provisions should be brought to the notice of all concerned by displaying on a notice board at a prominent place at the work-spot. The person responsible for compliance of the safety code shall be named therein by the CONTRACTOR. viii) To ensure effective enforcement of the rules and regulations relating to safety precautions, the arrangements made by the CONTRACTOR shall be open to inspection by the Welfare Officer, ENGINEER-IN- CHARGE or safety Engineer of the Administration or their representatives. ix) Notwithstanding the above clauses there is nothing in these to exempt the CONTRACTOR for the operations of any other Act or rules in force in the Republic of India. The work throughout including any temporary works shall be carried out in such a manner as not to interfere in any way whatsoever with the traffic on any roads or footpath at the site or in the vicinity thereto or any existing works whether the property of the Administration or of a third party. In addition to the above, the CONTRACTOR shall abide by the safety code provision as per C.P.W.D. Safety code and Indian Standard Safety Code from time to time. 117 Care in handling inflammable gas: 117.1 The CONTRACTOR has to ensure all precautionary measures and exercise utmost care in handling the inflammable gas cylinder/inflammable liquids/paints etc. as required under the law and/or as advised by the fire Authorities of the EMPLOYER 118 Temporary combustible structures: 118.1 Temporary combustible structures will not be built near or around work site. 119 Precautions against fire: 119.1 The CONTRACTOR will have to provide Fire Extinguishers, Fire Buckets and drums at worksite as recommended by ENGINEER-IN-CHARGE. They will have to ensure all precautionary measures and exercise utmost care in handling the inflammable gas cylinders/ inflammable liquid/ paints etc. as advised by ENGINEER- IN-CHARGE. Temporary combustible structures will not be built near or around the work-site. (Sign & Seal of Bidder) Page 152 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED 120 Explosives: Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II 120.1 Explosives shall not be stored or used on the WORK or on the SITE by the CONTRACTOR without the permission of the ENGINEER-IN-CHARGE in writing and then only in the manner and to the extent to which such permission is given. When explosives are required for the WORK they will be stored in a special magazine to be provided at the cost of the CONTRACTOR in accordance with the Explosives Rules. The CONTRACTOR shall obtain the necessary license for the storage and the use of explosives and all operations in which or for which explosives are employed shall be at sole risk and responsibility of the CONTRACTOR and the CONTRACTOR shall indemnify the EMPLOYER against any loss or damage resulting directly or indirectly there from. 121 Mines act: 121.1 SAFETY CODE: The CONTRACTOR shall at his own expense arrange for the safety provisions as required by the ENGINEER-IN-CHARGE in respect of all labour directly employed for performance of the WORKS and shall provide all facilities in connection therewith. In case the CONTRACTOR fails to make arrangements and provides necessary facilities as aforesaid, the ENGINEER-IN- CHARGE shall be entitled to do so and recover the costs thereof from the CONTRACTOR. 121.2 Failure to comply with Safety Code or the provisions relating to report on accidents and to grant of maternity benefits to female workers shall make the CONTRACTOR liable to pay Company Liquidated Damages an amount not exceeding Rs.50/- for each default or materially incorrect statement. The decision of the ENGINEER-IN- CHARGE in such matters based on reports from the Inspecting Officer or from representatives of ENGINEER-IN-CHARGE shall be final and binding and deductions for recovery of such Liquidated Damages may be made from any amount payable to the CONTRACTOR from all the provisions of the Mines Act, 1952 or any statutory modifications or re-enactment thereof the time being in force and any Rules and Regulations made there under in respect of all the persons employed by him under this CONTRACT and shall indemnify the EMPLOYER from and against any claim under the Mines Act or the rules and regulations framed there under by or on behalf of any persons employed by him or otherwise. 122 Preservation of place: 122.1 The CONTRACTOR shall take requisite precautions and use his best endeavors to prevent any riotous or unlawful behavior by or amongst his worker and others employed or the works and for the preservation of peace and protection of the inhabitants and security of property in the neighborhood of the WORK. In the event of the EMPLOYER requiring the maintenance of a Special Police Force at or in the vicinity of the site during the tenure of works, the expenses thereof shall be borne by the CONTRACTOR and if paid by the EMPLOYER shall be recoverable from the CONTRACTOR. 123 Outbreak of infectious diseases: 123.1 The CONTRACTOR shall remove from his camp such labour and their facilities who refuse protective inoculation and vaccination when called upon to do so by the ENGINEER-IN-CHARGE's representative. Should Cholera, Plague or other infectious diseases break out the CONTRACTOR shall burn the huts, beddings, (Sign & Seal of Bidder) Page 153 of 154 granularity=word contentanalysis={punctuationbreaks=false dehyphenate=false} layoutanalysis={tabledetect=0 layoutdetect=0} BHAGYANAGAR GAS LIMITED Tender for Operations and Comprehensive Annual Maintenance Contract (AMC) of Delta Make Compressors of BGL in Hyderabad & Vijayawada. Bid Document No. BGL/423/2018-19 VOLUME I OF II clothes and other belongings or used by the infected parties and promptly erect new huts on healthy sites as required by the ENGINEER-IN-CHARGE failing which within the time specified in the Engineer's requisition, the work may be done by the EMPLOYER and the cost thereof recovered from the CONTRACTOR. 124 Use of intoxicants: 124.1 The unauthorized sale of spirits or other intoxicants, beverages upon the work in any of the buildings, encampments or tenements owned, occupied by or within the control of the CONTRACTOR or any of his employee is forbidden and the CONTRACTOR shall exercise his influence and authority to the utmost extent to secure strict compliance with this condition. In addition to the above, the CONTRACTOR shall abide by the safety code provision as per C.P.W.D. safety code and Indian Standard Code framed from time to time. (Sign & Seal of Bidder) Page 154 of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